36 Electrical Standards Expert Witnesses Found

Electrical Engineering, Telecommunications - Forensic Engineering, Garage Doors, UL 325, transformers, HVAC systems, origin and cause, fire investigations, cellular and television towers, fiber optic cables, National Electrical Code, NEC, NESC, National Electrical Safety Code, lightning damage, electrocution, personal injury, code compliance

I have served as a consultant on damage claims related to a wide variety of electrical systems, including transformers, switchgear, busway and cable systems, diesel generators, electric and gas-fired furnaces, uninterruptible power supplies, HVAC equipment, chillers, vehicle systems, recreational vehicles, smart-home systems and many others. I have extensive experience evaluating damage in commercial and residential settings, and am equipped to perform insulation testing when required. I have consulted on a number of cases involving industrial and commercial machinery, residential electrical systems, and various personal injury cases....

Fire, Engineering - Fire Protection Engineering, Arson, Smoke Detection, Fire Alarm, Fire detection, Smoke and CO alarms, Forensic engineering, Fire spread analysis, Fire recreation, Origin and cause investigation, Consumer products, Failure Analysis, Modeling

...Dan Gottuk is the President of Gottuk Engineering after a 30 year career with Jensen Hughes, with which he still maintains a relationship with a team of over 100 experts providing expert witness and failure analysis services for a range of specialties associated with fires and explosions, mechanical, electrical, construction, codes and standards, materials, chemical, metallurgical, process safety and concrete. Other specific service areas include: Arson Investigation, Origin & Cause Investigations; Fire Spread Analysis; Fire Modeling; Fire Testing; Sprinkler Systems; Inadvertent Discharge; Corrosion; Fire Alarm Systems; Smoke Alarms; Carbon Monoxide; Kitchen Hood Suppression; Battery Fires (including Lithium and Lithium Ion); Building Insulation Fires; Spray-Applied Fire-Resistive Materials (SFRM); Structural Fire Protection; Combustible Dust Hazards; Dust Explosions; Laboratory & Evidence Examination. Dr....

Real Estate - Personal Injury, Slip, Trip, Fall, Reconstruction-Photo/Video, Title 24 Part 2 - California Building Code, Title 24, Part 3 NFPA 70, National Electrical Code (NEC), Americans with Disabilities Act (ADA), Permits/ Construction Docs, Realtor Disclosure, Misrepresentation, Negligence, Affirmative Duty

DBI Expert Witness is a commercial real estate Consulting Firm that offers services, including workplace safety and health standards of care and OSHA compliance services. • Litigation consultation services and trial testimony • Expert consultation on public safety, building compliance and personal injury • Building Code violations and property owner negligence • California Building Standards Code (Title 24) • Application, interpretations, compliance and industry consensus standards of the OSH ACT of 1970 • Lease obligations and Landlord/Tenant default Extensive experience in asset and property management issues related to management operations, leasing, Landlord/Tenant disputes, slip & falls, property inspection and maintenance, security, fiduciary and affirmative duties, plus standards of care for commercial facilities. Dr....

Safety, OSHA - Construction, Mining, Workplace Inspections, Crane, Rigging, EM 385-1-1, First Aid/CPR/AED, General Industry, Accident Investigation, Safety Training, Compliance, Workplace Conditions, Fall Protection, Powered Industrial Trucks, Machine Guarding, Excavation, Trenching, Scaffolds, Multi-Employer

.... • Construction training and safety standards for power tool injury. Safety and Slip Trip & Fall, EM 385-1-1, OSHA, (SSHO), Competent Person, First Aid/CPR/AED Instructor Trainer, Certified Safety Professionals (CSP) designation with the Board of Certified Safety Professionals, Certified Safety and Health Professional (CSHP) in the State of Hawaii. Construction and General Industry, Accident Investigation, Fall Protection, Forklift, Aerial Lift, Boom Lift, Scissor Lift, Machine Guarding, Amputation, Struck By, Caught Between, Scaffold, Ladder, Roofing Safety, Amputation, Excavation/Trenching, Crush, Traffic Control, Multi-Employer, Cranes, Confined Space, Demolition, Directional Drilling, Electric, Equipment, Machine Guarding, Excavation, Paving, Power Tools, Rigging, Shoring. Successfully implemented numerous nationally and internationally accepted safety management systems involving multiple training programs, inspection tools and accident investigation methods....

Construction, Construction Defects - General Construction, Framing, Building Envelope, Waterproofing, Electrical, HVAC, Concrete, Residential Construction, Multi Family Dwelling, Single Family Dwelling, Commercial Construction, Finish , Contract Scope, Cost to Repair, Site development, Architectural Design, Utility , Gas, Solar, Fire

...Cotton holds several active licenses from the state of California, specifically plumbing, electrical, and carpentry. For each of these credentials, Mr. Cotton accrued qualifying time under the guidance of licensed experts in each trade and passed all required testing. He has been in construction since the early 2000’s, solidly grounding his vast knowledge and expertise. Mr. Cotton serves as an expert witness in many construction-related matters. As VP of Reconstruction and Senior Consultant at Blackstone Global based in Walnut Creek CA, Mr. Cotton performs construction defect and litigation services with a team of highly qualified experts. Services focused on include: Testing and analysis of construction defects. Destructive testing (ASTM standard testing doctrines). Field inspection services. Comprehensive report generation. Contract analysis: scope of work and cost. Cost of repair estimating. Photographic documentation and UAV drone imaging....

Real Estate, Premises Liability - Property management, broker, agent, landlord/tenant, apartment, residential, commercial, HOA, wrongful eviction, habitability, standard of care, premises liability, slip/trip/fall, inspection, building codes, electrical codes, health and safety, maintenance, personal injury, rent control, damages

Edrington and Associates are residential investment property specialists. We maximize value and solve complex real estate challenges for our clients, who are owners, developers, and buyers/sellers of rental housing. We are active practitioners in the field in addition to our expert witness work where we primarily serve landlord/tenant and insurance defense attorneys. Steven Edrington is a Certified Commercial Investment Member (CCIM), Certified Property Manager (CPM), Certified Forensic Litigation Consultant (CFLC), and an ICC Residential Building Inspector. Philip Barthman is an ICC Combination Inspector, electrician, and former Alameda County Building Inspector. We are frequent presenters to the Bar Association of San Francisco, Alameda County Bar Association, Bridge Association of Realtors, San Francisco Apartment Association, and East Bay Rental Housing Association on topic including Issues of Habitability, Adding/Legalizing Units, and Oakland Rent and Eviction Controls.

Automotive Engineering, Telecommunications - Automotive Systems, ADAS, Autonomous Vehicles, Self-Driving Cars, Adaptive Cruise Control, Blind Spot Monitoring, Lane Keeping, Automotive Software, Automotive Electronics, Collision Avoidance, Telecommunications, Networking, Carrier Ethernet, DSL, Wi-Fi, 5G, Wireless Transceivers, Telecom Standards

...He is the author or co-author of one book, 6 book chapters, 24 articles in refereed technical journals, 60 papers in refereed technical conferences, and multiple standards contributions. He was the plenary speaker at major technical conferences, and an invited speaker at more than 40 industrial and academic venues in 12 countries across 4 continents. He has significant expert witness experience in patent infringement and product liability cases in the automotive and telecommunication areas; 100% of his cases resulted in a win or a very favorable settlement for his clients. In 2017, he was the lead expert witness in a case that resulted in a $25M jury award for his clients; this decision was later upheld on appeal. His deep technical expertise allows him to analyze patents and products in detail, and explain clearly (in expert reports, depositions, and court testimony) the main issues that the judge and jury need to internalize in order to comprehend the essence of the case....

Construction Defects, Electrical Engineering - General Construction, Framing, Building Envelope, Waterproofing, Electrical, HVAC, NFPA, Generators, Design, Solar, Fire, Gas, Hybrid Water Heaters, Contract Scope, Cost to Repair, Fire, Industrial Controls, Electrocutions, Shocks, Electrical Fires

...Scerbo has over 3 decades of experience in the construction industry, including 23 years as a licensed General, Electrical & HVAC Contractor in the state of CA. Mr. Scerbo's diverse background serves as a well-balanced platform with extensive expertise in Building Envelope, Mechanical, Electrical & Plumbing (MEP) disciplines. He has dedicated his professional career to providing accurate, impartial and credible work, including testimony to support legal proceedings. He serves as a construction consultant and expert for construction defect litigation. Experiences include cost evaluations and coverage determination, project management, construction defect analysis, code and industry standards review and analysis, litigation support, along with consulting and peer review for single family, multifamily, hospitality and commercial construction. Mr. Scerbo serves as an expert witness in many construction-related matters....

Building Inspection, Construction Defects - home inspection, landlord tenant disputes, substandard housing, construction, building code violations, building inspection, code violations, fire safety, property maintenance, code violations, standards of care, code enforcement, housing inspection, commercial inspection, residential inspection,

...Watts has a diverse inspection background performing thousands of residential, commercial and industrial inspections in evaluation of all construction trades including structural, mechanical, electrical, and plumbing code compliance and construction defects. Mr. Watts has been employed by two government agencies as a Certified Building Inspector and Code Enforcement Officer. As the owner of American Dream Home Inspection, performed thousands of property inspections for home buyers in real estate transactions. Since 2007, he has provided litigation support for dozens of cases for law firms with an approximate 50/50 plaintiff and defendant client ratio. Mr. Watts has testified numerous times in depositions and court trials....

Energy, Engineering - Solar,PV,Photovoltaics,Energy,Batteries,Construction,Electric Utility,Intellectual Property,Patent,Project Development,Electrical Engineering,Asset Management,Contracts,Electricity,Generation,Renewable Energy,Solar Energy,Solar Power,Solar Installation

...Specific areas of expertise, listed below, include energy technologies, markets, policy, finance, project development, planning and execution, project management, and codes and standards. Weiner is adept at unpacking complex topics into simple language that all parties can understand. Since 2007, Weiner is a certified member of the North American Board of Certified Energy Practitioners (NABCEP) in good standing. Weiner has also taught advanced solar system design and project management at UC Berkeley....

Electrical Engineering, Telecommunications - electrocution, electronics, networks, wireless, cellular, 5G, GPS, radar, LTE, cell phones, cell towers, base stations, SMS, quality sciences, applied research, RF, interference, radio, satellite, Internet, control systems, instrumentation, appliances, RFID, mobile, software, geolocation, geofencing

Mark McFarland, PE, DFE, is a licensed and Board Certified electrical and telecommunications engineer. He provides expert consulting to plaintiff and defense counsel on civil and criminal cases nationwide. Mark's practice covers a wide range of cases, typically involving electrical, electronic, software, cellular, GPS, and telecommunications evidence. He has worked with lawyers in several fields including: wrongful death, personal injury, product liability, securities fraud, homicide, sex trafficking, medical malpractice, class action, insurance claims, patent litigation, contract disputes, and more. Mark has worked dozens of cases and has testified in court and depositions for civil and criminal trials. Many of the cases he's worked have settled on his expert report. Contact Mark at Discovery Engineering when you have litigation involving electrical, electronic, software, cellular, or GPS evidence....

Transportation, Safety - Slip Trip & Fall, Pedestrian & Bicycle Safety, Railroad Safety, Bus Safety, Biomechanics & Human Factors, FELA & OSHA, Elevators & Escalators, Traffic Engineering, Transportation Engineering, Transportation Safety, Transportation Rules & Regulations, Transportation Expert Witness

...He is a Professional Engineer in New York and New Jersey, and a member of the American Institute of Certified Planners; American Planning Association; American Society of Civil Engineers (Fellow, Transportation Education and Safety Committees); Association of Pedestrian and Bicycle Professionals; Institute of Transportation Engineers; American Society of Safety Engineers; National Association of Railroad Safety Consultants and Investigators; American Society of Transportation and Logistics; American Railway Engineering and Maintenance of Way Association (Committees 11 and 12, Facilities and Structures Subcommittee); American National Standards Institute, ASTM, International, Member Technical Committee F13 and Task Group D11.20.01 (Recycled Rubber); American Public Transit Association, Technical Committees (Public Safety, Rail Safety and Security, Rail Safety, Bus Safety and Rail Standards Policy and Planning); Human Factors and Ergonomics Society, Surface Transportation Technical Group;...

Fire, Engineering - Fire Protection Engineering, Arson, Smoke Detection, Fire Alarm, Fire detection, Smoke and CO alarms, Forensic engineering, Fire spread analysis, Fire recreation, Origin and cause investigation, Consumer products, Failure Analysis, Modeling

...Dan Gottuk is the President of Gottuk Engineering after a 30 year career with Jensen Hughes, with which he still maintains a relationship with a team of over 100 experts providing expert witness and failure analysis services for a range of specialties associated with fires and explosions, mechanical, electrical, construction, codes and standards, materials, chemical, metallurgical, process safety and concrete. Other specific service areas include: Arson Investigation, Origin & Cause Investigations; Fire Spread Analysis; Fire Modeling; Fire Testing; Sprinkler Systems; Inadvertent Discharge; Corrosion; Fire Alarm Systems; Smoke Alarms; Carbon Monoxide; Kitchen Hood Suppression; Battery Fires (including Lithium and Lithium Ion); Building Insulation Fires; Spray-Applied Fire-Resistive Materials (SFRM); Structural Fire Protection; Combustible Dust Hazards; Dust Explosions; Laboratory & Evidence Examination. Dr....

Automotive, Products Liability - wiring, electrical, fire, defect, design, failure, electronics, battery, motor, module, engineering, connector, instrument, cluster, speedometer, HVAC, charging, alternator, starter, validation, vehicle, automotive, forensic,

...Expert in Failure Analysis and Forensic Engineering of automotive electrical fires and accidents caused by electrical, wiring or electronics due to defects, design flaws or assembly errors. M.I.T. BSEE (ME minor), UD Mercy (MIT curriculum) MS in Product Development and Systems Engineering, and UD Mercy EngD Doctoral coursework completed. Over forty years of automotive electronic and mechanical product design, development, manufacturing and field failure analysis experiences. A Six-Sigma Black belt trained strategic and systems thinker, achieved millions of dollars in cost and quality improvements by designing and launching various electronic modules and sub-systems, including Infotainment, Climate Controls, Electronics and Wiring. As a Ford Quality Supervisor, used my prior 23 years of design, warranty analysis and service experiences to coach electronic module and wiring engineers to improve their designs....

Safety, OSHA - Construction, Mining, Workplace Inspections, Crane, Rigging, EM 385-1-1, First Aid/CPR/AED, General Industry, Accident Investigation, Safety Training, Compliance, Workplace Conditions, Fall Protection, Powered Industrial Trucks, Machine Guarding, Excavation, Trenching, Scaffolds, Multi-Employer

.... • Construction training and safety standards for power tool injury. Safety and Slip Trip & Fall, EM 385-1-1, OSHA, (SSHO), Competent Person, First Aid/CPR/AED Instructor Trainer, Certified Safety Professionals (CSP) designation with the Board of Certified Safety Professionals, Certified Safety and Health Professional (CSHP) in the State of Hawaii. Construction and General Industry, Accident Investigation, Fall Protection, Forklift, Aerial Lift, Boom Lift, Scissor Lift, Machine Guarding, Amputation, Struck By, Caught Between, Scaffold, Ladder, Roofing Safety, Amputation, Excavation/Trenching, Crush, Traffic Control, Multi-Employer, Cranes, Confined Space, Demolition, Directional Drilling, Electric, Equipment, Machine Guarding, Excavation, Paving, Power Tools, Rigging, Shoring. Successfully implemented numerous nationally and internationally accepted safety management systems involving multiple training programs, inspection tools and accident investigation methods....

Mechanical Engineering, Equipment & Machinery - Cranes & Hoists, Printing & Packaging Equip, Bowling Machinery, Agricultural Equip, OSHA, Machinery Maintenance Practices, Conveyors, Hand & Power Tools, Ladders, Workplace Safety, Slip Trip & Fall, Premises Liability, Safety, Warnings & Label Evaluation, Metalworking Equip, Aerial Work Platforms

...In addition, I serve on the Executive committee which reviews and votes on all ladder-related standards in the A14 family, the A14 Steering Committee, the Labeling Task Force and the Ladder Accessories Sub-committee. I have an extensive background in the Bowling Industry having served my Mechanical Engineering internship with the Brunswick Corp. Automatic Pinsetter division. I have also had ownership interest in two Chicagoland bowling centers. I have performed mechanical and electrical maintenance on Automatic Pinsetters since 1974 in addition to having provided instruction to several dozen apprentice mechanics in the operation of the Pinsetter and related bowling equipment and continue to do so today. I continue to provide expert witness and consulting services to both major bowling equipment manufacturers including Brunswick and Qubica/AMF for a variety of safety-related incidents that have occurred in bowling centers throughout the United States....

OSHA, Safety - OSHA, Industrial Accidents, Safety, Industrial Hygiene, Loss Control, Risk Management, Slip Trip & Fall, Construction Accidents, Manufacturing Accidents, Insurance, Investigations

...Approximately 55% of my litigation cases are related to slips, trips, and falls. 45% are related to caught-in, struckby, and electrical. My litigation average is 40% defense and 60% plaintiff. 59 submitted reports, 34 depositions, one (1) arbitration, and three (3) jury trials. During my 25 year career with OSHA Compliance, I testified in numerous OSHA contest hearings....

Electricity, Safety - workplace electrical safety, arc flash, electrical safety management, electrical codes & standards, NFPA70E, National Electrical Code, electrical injury, electrocution, electrical reliability, electrical maintenance, electrical construction, occupational electrical safety, OSHA, NESC, electric shock

I am an expert, author, speaker, and educator in occupational electrical safety. I received my BSEE from VA Tech in 1973. My 45+ year career with DuPont focused on electrical safety in the construction, operation, and maintenance of DuPont facilities worldwide. My responsibilities included improving management systems, competency renewal, work practices, and the application of technologies critical to electrical safety performance in all DuPont operations. I have published more than 90 peer-reviewed papers and magazine articles on occupational electrical safety. I have received awards from leading institutions recognizing my work to advance the practice of electrical safety. I am an adjunct faculty member in the graduate school of Advanced Safety Engineering and Management (ASEM) at the University of Alabama at Birmingham (UAB). At UAB, I teach Prevention through Design, Engineering Ethics, and Electrical Systems Safety which I developed for the ASEM curriculum....

Fire, Engineering - Fire Protection Engineering, Arson, Smoke Detection, Fire Alarm, Fire detection, Smoke and CO alarms, Forensic engineering, Fire spread analysis, Fire recreation, Origin and cause investigation, Consumer products, Failure Analysis, Modeling

...Dan Gottuk is the President of Gottuk Engineering after a 30 year career with Jensen Hughes, with which he still maintains a relationship with a team of over 100 experts providing expert witness and failure analysis services for a range of specialties associated with fires and explosions, mechanical, electrical, construction, codes and standards, materials, chemical, metallurgical, process safety and concrete. Other specific service areas include: Arson Investigation, Origin & Cause Investigations; Fire Spread Analysis; Fire Modeling; Fire Testing; Sprinkler Systems; Inadvertent Discharge; Corrosion; Fire Alarm Systems; Smoke Alarms; Carbon Monoxide; Kitchen Hood Suppression; Battery Fires (including Lithium and Lithium Ion); Building Insulation Fires; Spray-Applied Fire-Resistive Materials (SFRM); Structural Fire Protection; Combustible Dust Hazards; Dust Explosions; Laboratory & Evidence Examination. Dr....

Medical Management, Internal Medicine - Hospital Liability, Hospital Negligence, Hospital Administration, Peer Review, Delayed Diagnosis, Missed Diagnosis, EMTALA, Sepsis, Falls, Sexual Assault, Infection Prevention, Credentialing, Privileging, Anticoagulation, Wrong Site Surgery, Medication Error, Safe Discharge

...Extensive experience in developing programs for hospital quality, patient safety, and peer review and addressing issues such as Joint Commission Standards, Regulatory Quality Requirements, DNV Standards, Credentialing and Privileging, Medical Ethics, Infection Prevention, Medication Safety, Anticoagulation Safety, Wrong Site Surgery, Patient Discharge, Patient Admission, and Patient Transfer. Board Certified in Internal Medicine. Distinguished Fellow of the American College of Physicians. Remains clinically active as a part time attending physician. Experience as Chief Medical Officer. Former electrical engineer working as aviation engineer in the aerospace industry. Experienced expert witness - have reviewed dozens of cases and testified at both deposition and trial.

Engineering, Transportation - Failure Analysis, Automotive Design Analysis, Accident Reconstruction, Material Handling, Trailer Loading, Forensic Logistics Analysis, OSHA Compliance/Standards, Warning Labels, Machine Guarding, Stamping Presses, Injection Molding Presses, Backhoes, Loaders, Industrial Accidents, Appliance Leaks.

...Product Design senior engineer for design and test of automotive body, electrical, and mechanical components. In-plant Quality Manager, Senior Manufacturing Engineer, Senior Engineer of Manufacturing Process Analysis, including metal stamping presses, robotic welding equipment, injection molding presses. Member, National Society of Professional Engineers, Michigan Society of Professional Engineers, and National Academy of Forensic Engineers. 11 patents. 27 years Adjunct Professor in Manufacturing Engineering, Schoolcraft College. Forensic Engineering, investigation of mechanical design defects, product and design failure analysis, patent disputes, product liability, product defects. Vice President of Design and Manufacturing Engineering for 3 major corporations....

Engineering, Safety - fire, shock, burn, appliance, product, design, test, code, safety, failure, analysis, warning, instruction, literature, product safety, containment, inspection, litigation, product liability, expert

...Qualifications: Registered professional engineer in the state of Michigan Certified fire and explosion investigator (CFEI) Master certified in design for safety Master certified in force failure testing Certified in experimental statistics and statistical process control Member of the UL Standards Technical Panel for appliance codes related to clothes washers and dryers I worked in the consumer goods industry in appliances for over 28 years, which gave me the opportunity to serve on the dryer safety committee for the American Home Appliance Manufacturers (AHAM), as well as work extensively with Underwriters Laboratory ( UL) and CSA. Recognized as a significant knowledge source in the US on dryer fires and their causes, I was instrumental in the development of the clothes dryer drum containment standard recently implemented by all US codes agencies. I am certified to run both the UL and ANSI dryer drum fire containment test as well as the dryer base fire containment test....

Safety, Agriculture Engineering - Accidents, Auto ADAS, Agriculture, Battery Fires, Cannabis Processing, Chemical Exposure, Child Safety, Construction, Electrocution, Ergonomics, Fitness Equip, Fires/Explosions, HazCom, Human Factors, HVAC, Mechatronics/Nano, Medical Devices, OSHA, Recalls, RV/ATV, Slip/Fall, Vapes, Warnings/Label

...The span of our collective academic and experiential expertise includes the Mechanical, Electrical, Chemical, Agricultural, Industrial, Human Factors, Ergonomic and Safety fields of engineering. Miller Engineering’s principle engineers wrote the original books on warnings and instructions, have published in several other areas, have participated in product designs and patents, and have analyzed, reconstructed and/or animated numerous types of accidents. Miller Engineering also designs and operates hydroelectric and solar energy sources within their agricultural, forestry, marine, and cattle subsidiary operations in Idaho and Oregon, lending to unique hand-on expertise in these areas. We are known for our staff’s thorough, detailed documentation and portrayal of accident sequences and the surrounding environmental circumstances. Dr. James Miller, PE—Founder of Miller Engineering and Emeritus Professor at the University of Michigan – Engineering....

Motorcycle, Failure Analysis - Accident Reconstruction, All Terrain Vehicle, UTV, Side by Side, Electrical Engineer, Throttle Design, Dealership, Snowmobile, Power Steering, Consultant, Fire, Electronics, Accessory, Rollover, Polaris, Ranger, Speed Sensor, Root Cause Analysis, Trade Practices, Patent, Arctic Cat, Trademark, ATV

...Active consulting practice in off-road vehicle regulatory compliance, off-road vehicle safety and design standards, primary market research, product planning, product development and sales both into the dealer channel and B2B. 6 United States patents relating to various electronic systems on ATVs, UTVs and Snowmobiles. Expert at root cause analysis of product failures. Expert in trade practices. A keen understanding of the UTV market, nuances in technologies, dealer channel development, and competitive factors. Expert at analysis of designs on motorcycles, ATVs, UTVs, side-by-sides and snowmobiles including: steering systems, throttle levers, throttle pedals, lighting, wire harness, wiring, winches, engine control systems, sensors, runaway vehicles, fires, overheating, electric vehicle powertrains, batteries, rollovers, rider behavior, switches. I use diagnostic tools to aid with root cause analysis, data capture and accident reconstruction....

Information Technology, Telecommunications - Cloud Computing, Computer, Construction Claims, Contracts, Data Center, Engineering, Fiber Optic, Forensic Engineering, Internet, Intellectual Property, Life Safety, Network, Operations, Outsourcing, Project Management, Service Level Agreement, Systems Implementation, Telecom, Trade Secret

...Publications & Awards ♦ANSI/BICSI 002, Data Center Design & Implementation Best Practices Standard, Author/Editor ♦ANSI/BICSI 009, Data Center Operations Standard, Chair/Author/Editor ♦Data Center Handbook, Wiley Publishing One of 50 Subject Matter Experts from around the world that authored the content, providing the fundamentals, technologies, and best practices in designing, constructing & managing mission critical, energy efficient data centers....

Engineering, Construction Defects - Standard of care, construction defect, construction delay, engineering, mechanical engineering, HVAC, project management, construction schedule analysis, manufacturing, product liability, power, refrigeration, fire, explosion, automotive, forensics, failure analysis, engineering standard of care

...Developed an expert opinion and report for general construction issues, constructability, design revisions, and corresponding delay analysis for mechanical, HVAC, electrical, smoke and fire, structural, security and building automation systems. Reviewed findings with multi – discipline experts for mediation, leading to a negotiated settlement favorable to our client. Municipal Building/Facility - Northern NJ - Evaluated and provided expert witness mediation testimony regarding a $3M construction delay claim by general contractor against municipal facility concerning an $8M renovation and new construction project. Analysis included review of plaintiff’s claim, project schedules, critical path & time impact considerations, delays, pay applications, contract terms, change orders, consequential & liquidated damages, lien and bond issues, correspondence and numerous other project documents. Guided mediation to quickly develop a very favorable settlement for our client....

Aquatics Safety, Risk Management - Pools, Swimming Pools, Water Death, MSDS, Drowning, Drowning Investigations, Drowning Prevention, Chemical Exposure, Chemical Fires, Chemical Hazards, Chemical Incompatabilities, Chemical Product Safety, Chemical Risks, Chemical Spills, Chlorine, Hazardous Chemical Reactions, Hazardous Chem.

Rutgers University, New Brunswick, NJ, Garden State Scholar PHTA Certified Pool/Spa Operator (CPO) Instructor Certification PHTA Certified Pool/Spa Operator (CPO) Certification PHTA Certified Pool Operator & Inspector PHTA Advanced Service Technician (AST) Instructor PHTA Certified Building Professional (CBP) & Course Instructor PHTA Certified Service Professional (CSP) & Course Instructor PHTA Certified Service Technician Instructor (CST) & Course Instructor PHTA Certified Maintenance( Specialist (CMS) & Course Instructor PHTA Certified Building Professional (CBP) Review Course Instructor PHTA Professional Pool & Spa Operator (PPSO) & Instructor PRPS Swimming Pool Pesticide Instructor Certification Pool & Spa Heater Service Training, Pool and Spa Electrical Qualification Training OSHA's Competent Person Training Lead instructor for NESPA VGB training team granted by CPSC Assisted NJ and MA State Bathing Code Development Train NJREHS on Water Chemistry and Pool Inspections PHTA-1 and...

Engineering, Forensic Science - Forensic Engineering, Explosions, Electrical Engineering, Mechanical Engineering, Product Liability, Fires, Fire Protection, Appliances, Construction, Building Defects, Failure Analysis, Laboratories & Testing, Building Defects, Plumbing

Steven Pietropaolo has a Bachelor Degree of Engineering in Electrical Engineering and a Master of Science Degree in Mechanical Engineering from Manhattan College. Mr. Pietropaolo is a Licensed Professional Engineer (P.E.) in the State of New York, amongst many others. He is a Certified Fire and Explosion Investigator, a Certified Fire Investigator Instructor, a Certified Forensic Consultant and Certified Forensic Professional Engineer. He is a Fellow of the American College of Forensic Examiners Institute. He is Board Certified in Forensic Engineering by the National Academy of Forensic Engineers. He has 30+ years of hands on engineering experience including electrical, mechanical, materials, safety, human factors, fire protection, and construction. He has knowledge of codes and standards used in construction and industry including building codes and safety codes....

Safety, OSHA - Construction, General Industry, Equipment & Machinery, Forklifts, Slip, Trip & Fall, Lockout/Tagout, Scaffold, Aerial Lift, Crane, Rigging & Signaling, MSHA, Accident Investigation, Construction Safety, Forklifts, Ladders, Machine Guarding, Dropped Objects, Struck-by, Crush Hazards, Personal Injury

...Certified Independent STAR Assessor American Society of Safety Professionals (ASSP) Member Experienced in: -Occupational safety and health policies & standards -Personal injury, catastrophic injury, and fatality cases -Multi-employer worksites -Crane accidents -Crane safety -Mobile and overhead cranes -Rigging & Signalperson -Trenching and excavation -Confined space -MSHA Part 48 & 46 -Contractor safety -Chemical safety including lead, silica, hexavalent chromium, and ammonia safety -Noise -Fall protection -Scaffolding -Forklift, Aerial lift -Accident investigations -Struck-By/Caught-Between Hazards -Electrical Safety *Available nationwide Joe DeFranco, CSP has been a safety professional since 1996 and is currently President and Owner of Safety Consulting Specialists, Inc. headquartered in Raleigh, NC. Joe develops safety and health programs and provides safety training, consulting, and crane safety services to a wide variety of industries nationwide....

Mechanical Engineering, Products Liability - Snowplow, snow, ice, snow and ice removal, salt spreader, towing, pintle hook, ball mount, lunette, trailer, truck, snow plow, gritter, cartridge valve, hydraulics, aftermarket truck accessories

...Areas of expertise include: • Snowplows and related mechanical, hydraulic and electrical systems • Salt Spreaders and related mechanical, hydraulic and electrical systems • Truck Towing Products – Pintle Hooks, Couplers, Hitch Balls and relevant SAE standards • Truck Accessory Design and Mounting • Dealer Training and Technical Communication • Product Development, Engineering and Lifecycle Management

Engineering, Construction Defects - Standard of care, construction defect, construction delay, engineering, mechanical engineering, HVAC, project management, construction schedule analysis, manufacturing, product liability, power, refrigeration, fire, explosion, automotive, forensics, failure analysis, engineering standard of care

...Developed an expert opinion and report for general construction issues, constructability, design revisions, and corresponding delay analysis for mechanical, HVAC, electrical, smoke and fire, structural, security and building automation systems. Reviewed findings with multi – discipline experts for mediation, leading to a negotiated settlement favorable to our client. Municipal Building/Facility - Northern NJ - Evaluated and provided expert witness mediation testimony regarding a $3M construction delay claim by general contractor against municipal facility concerning an $8M renovation and new construction project. Analysis included review of plaintiff’s claim, project schedules, critical path & time impact considerations, delays, pay applications, contract terms, change orders, consequential & liquidated damages, lien and bond issues, correspondence and numerous other project documents. Guided mediation to quickly develop a very favorable settlement for our client....

Transportation, Industrial Design - wheelchair transportation, biomechanics, public transit, railcar boarding, accessible air travel, wheelchair securement, wheelchair restraint, seatbelt, crash safety, ergonomics, accessibility, paratransit, wheelchair lift, medical device, ramp, school bus, walker safety, warnings, usability, ADA

...Dr. van Roosmalen has not only educated and trained others on wheelchair safety but has also designed electrical mechanical systems to enhance accessibility and transportation safety. She played a pivotal role in ANSI RESNA and ISO standards committees, co-authoring wheelchair standards on public transportation safety. As the Principal and founder of LINC Design LLC, Dr. van Roosmalen has conducted in-vehicle investigations and created training materials for major insurance underwriters of wheelchair-accessible paratransit systems. With over 20 years of accessible transportation experience in both private and public sectors, she is well-versed in safety systems and standards relevant to accessible transportation....

Fire, Engineering - Fire Protection Engineering, Arson, Smoke Detection, Fire Alarm, Fire detection, Smoke and CO alarms, Forensic engineering, Fire spread analysis, Fire recreation, Origin and cause investigation, Consumer products, Failure Analysis, Modeling

...Dan Gottuk is the President of Gottuk Engineering after a 30 year career with Jensen Hughes, with which he still maintains a relationship with a team of over 100 experts providing expert witness and failure analysis services for a range of specialties associated with fires and explosions, mechanical, electrical, construction, codes and standards, materials, chemical, metallurgical, process safety and concrete. Other specific service areas include: Arson Investigation, Origin & Cause Investigations; Fire Spread Analysis; Fire Modeling; Fire Testing; Sprinkler Systems; Inadvertent Discharge; Corrosion; Fire Alarm Systems; Smoke Alarms; Carbon Monoxide; Kitchen Hood Suppression; Battery Fires (including Lithium and Lithium Ion); Building Insulation Fires; Spray-Applied Fire-Resistive Materials (SFRM); Structural Fire Protection; Combustible Dust Hazards; Dust Explosions; Laboratory & Evidence Examination. Dr....

Electrical Engineering, Fire - Transformer, motor, generator, UPS, circuit breaker, switchboard, electrical fire, electrical insulation failure, short circuit, fault current, Arch flash, fire alarm, field investigation.

Highly-experienced registered electrical engineer in the States of California and Texas. Currently serves as Senior Engineer for Travis County Sheriff's Office. Duties include but not limitted to: equipment failure analysis, writing technical reports, writing business case, project budget preparation, project managment, review and recommend expert solutions, electrical saftey, energy savings, promotes clean energy systems design for the 130 acres of Travis County Correctional Complex and Travis County Jail. Worked internationally (Bangladesh, Malaysia, Brunei Darussalam and the USA). Experienced in applying British Standards, International Building Code, National Electrical Code (NEC), National Fire Alarm Code (NFPA), National Electrical Safety Code (IEEE SA) etc....

Mechanical Engineering, Forensic Science - Electrical Engineering, Energy, Equipment & Machinery, Failure Analysis, Fire, Laboratories & Testing, Oil and Gas, Products Liability, Product, Plumbing, Leak, Warnings & Labels, Guarding, CSST, Gas Explosions, Natural Gas, Propane, LPG, Forensic Engineering, Expert Witness

...Alabama Professional Engineer License #35693 -North Carolina Professional Engineer License #049314 -South Carolina Professional Engineer License #37169 -Virginia Professional Engineer License #0402061315 -Michigan Professional Engineer License #6201069726 -Minnesota Professional Engineer License #58020 EDUCATION: -BSME, University of Texas at Arlington, 1978 AFFILIATIONS: -MEMBER, American Society of Mechanical Engineers (ASME) -SENIOR MEMBER, National Academy of Forensic Engineers (NAFE) -MEMBER, National Council of Examiners for Engineering and Surveying (NCEES) -MEMBER, National Society of Professional Engineers (NSPE) -MEMBER, Texas Society of Professional Engineers (TSPE) -Pi Tau Sigma -Tau Beta Pi PRIMARY AREAS OF EXPERTISE: -Fire and Explosion Analysis Fuel Gas Fires and Explosions Residential, Commercial, Industrial Gas-Fired Equipment and Household Appliances Engineering Assistance for Fire Investigators -General Products and Equipment - Mechanical and Electrical...

Electricity, Safety - Electrical Safety, Electrocution, Electrical Arc Flash Burns, Utility Safety, Power Systems Safety, Utility Fall Protection, Transmission and Distribution Safety

As President of Workplace Safety Solutions, Inc. for over 20 years Lee has provided safety consultation services specializing in electrical safety to over 700 companies. With more than 45 years of experience in the electric field he has cultivated his expertise to build a solid consulting business. There are many electrical standards to sort through. Each case is unique and requires expertise in all of them. Lee has been teaching electrical standards classes for several OSHA Training Institutes for years and keeps current with the NEC changes by maintaining his electrician license. With 20 years field experience in the electric utility, powerline contacts are Lee’s specialty. But he also offers consultation, investigations, opinion reports and testimony for a variety of electrical safety issues from low voltage to ultra-high voltage....