115 Design Codes Expert Witnesses Found

Results Sorted Below by State

William Henry, PhD, NCARB RGA Design Forensics LLC

Alabama
Premises Liability, Disaster Recovery - Accident Investigation, Building Codes, ADA, Accessibility, Slip Trip & Fall, Forensic, Architecture, Engineering, E&O, Errors and Omissions, Construction Defects, Mold, Cruise Ship, Maintenance, Building Inspection, Insurance Claims, Disaster Recovery, Failure Analysis, Property Insurance
...Henry, our lead expert, utilizes three components in his case development: (1) a detailed timeline, (2) an analysis of the governing codes and documentation, and (3) the application of the facts to those governing codes. His reports and testimony are presented in a simple, clear manner that is easily understood. This approach has had a proven impact on the outcomes of past matters, whether in settlement, mediation, arbitration, or at trial. RGA Design Forensics’ main areas of expertise are premises liability, property insurance litigation, and architectural errors and omissions (E&O) claims. Premises Liability - Whether a slip trip & fall or some other incident, RGA works with both plaintiff and defense counsels to determine adherence to or deviation from governing codes, standards, and guidelines around the site. This information is vital in determining causality in a case....

William R. Acorn, P.E., DFE, FASHRAE, CFLC Acorn Consulting Services, LLC

Scottsdale, Arizona
Engineering, HVAC - HVAC and Refrigeration, Process and Power Piping, Plumbing Systems, Standard of Care in Design and Construction, Chemical Exposures in the Workplace, Cleanroom Design and Performance, Codes and Standards, Patent and Trade Secret Disputes, Data Centers
...As a consulting mechanical engineer, Bill provides project analysis, forensic reconstructions and litigation support services relating to the design, delivery and functioning of high-tech manufacturing facilities, semiconductor fabrication facilities, institutional laboratories, data centers, health care facilities and a variety of commercial buildings. He is a recognized expert in the evaluation of deficiencies in HVAC systems, cleanrooms, piping systems, refrigeration systems, construction defects and building and fire code compliance. He represents both plaintiffs and defendants. Bill has more than 45 years of experience as a professional engineer and owner's agent and is a recognized expert in assessing, evaluating, remediating and providing testimony on complex project design, construction and operational matters. His consulting expertise has been influential in shaping approaches to code compliance and life safety in semiconductor and similar advanced technology facilities.

Benjamin M Berschler, DMD Downtown Phoenix Dental Consultants LLC

Phoenix, Arizona
Dentist, Investigation - Dentist, Standard of Care, Dental Investigation, Dental IMEs, Implants, Office Construction & Equipment, Digital Impression Imaging, Infections, Crowns & Bridges, Diagnosis & treatment plan, Veneers, Trauma, Dentrix Software Management. Ledger and insurance analysis. Dental employment issues.
...Certified by the FBI National Crime Information Center (NCIC) in Unidentified & Missing Dental Coding, Owner/Operator of dynamic dental practices, personally working in the area of restorative general dentistry and associated with orthodontic, endodontic, oral surgery, implants, periodontal specialists, forensics, and digital dental labs....

David J. Brotman, FAIA Sunset Consultants

Scottsdale, Arizona
Architecture, Construction - Standard of Care, Construction Document, Real Estate, Slip, Trip & Fall, Delay, Defect, Change Order, Building, Design, Coordination, Code Compliance, Contract Document, Management, Contract Administration, Architectural Detailing, Commercial, Retail, Hotel, Office, Institutional, Construction
Fellow of the American Institute of Architects with over fifty years of experience. Twenty-five years with RTKL Associates Inc., one of the World’s largest Architect and Engineering Firms, and served as its Vice-Chairman. Past Planning Commissioner on the City of Malibu Planning Commission. Skills include all facets of Architectural Practice. Worldwide, multi-million dollar project experience includes retail, office, hotel, institutional, and mixed-use. Recently, qualified and served as a Standard of Care, Coordination, and Delay Expert in a case involving a major retail project. This included deposition and trial testimony.

Scott Greene Evidence Solutions, Inc.

Tucson, Arizona
Technology, Telecommunications - Cell Phone Forensics, Digital Forensics, Technology, EDR, ECM, Triangulation, Black Boxes, Electronic Medical Records, EHR,Investigation, Email, Cell phone apps, information Technology, intellectual property, internet, electronics, cyber security, Documents, hacking, data retrieval, Digital evidence
.... • Cell Phones • Call Data Records (CDRs) • Computer Systems • Databases • Digital Cameras • Digital Fraud • Digital Media • Digital Security • Documents • Electronic Logging Devices • Electronic Medical Records (EMR / EHR) • Email / E-mail • Fax Machines • Google Data • GPS Systems • GPS Records • Hacking Events • iCloud data • Intellectual Property • Internet Browsing History • Intrusions • Medical Systems • Other Electronic Devices • Password Cracking • Photo Copiers • Photos and Images • Printers & Fax Machines • Software Applications Custom & Commercial • Software Design & Development • Social Media • Source Code Analysis • Spreadsheets • Telematics Systems • Websites • And More TESTIFYING EXPERIENCE • Civil & Criminal • Special Master • Plaintiff and Defense • Insurance, Corporate, Family Law • Justice, Superior & District Courts as well as Arbitration Hearing CASE BREAKDOWN • Civil Defendants-30%• Civil Plaintiffs-50%• Criminal Defendants-20% Evidence Solutions, Inc. 2008* –...

Carl H. Josephson, PE, SE Josephson-Werdowatz & Associates, Inc.

Arizona
Structural Engineering, Engineering - Wood, masonry, steel, concrete structures. Construction defect, insurance litigation, professional liability claims. Seismic/wind design, code review, standard of care analysis. Also foundations, underpinning, retaining walls, and tie-backs. Extensive graphics and animations capabilities.
Josephson-Werdowatz & Associates (JWA), founded in 1988 and with licenses in thirty states, has provided structural design and construction defect investigations/evaluations across the United States and abroad. Structural evaluations included wood, masonry, steel, and concrete structures, with particular emphasis on seismic and wind design. JWA has experience working with specialty materials such as acrylic, aluminum, and glass as well. Evaluations also include code review and analysis, and standard of care analysis. JWA has extensive experience with geotechnical structures such as special foundations, underpinning, retaining walls, tie-backs, and soil nails, among others. JWA strives for a reasoned, accurate, and practical solution to structural engineering problems and deficiencies. Principal Structural Engineers Carl H. Josephson, PE, SE; Dan R. Werdowatz PE, SE; and Stephen P....

James Caylor, PE Caylor Engineering & Associates, PLLC

West Fork, Arkansas
Refrigeration, OSHA - Industrial process refrigeration, cold storage, ammonia, carbon dioxide, piping, insulation, design, design review, OSHA, EPA, mechanical code analysis.
...My engineering experience includes design and project management positions with a D/B contractor, a large food processor, an A&E firm (Deputy Director of the Food & Beverage Group) and my current consulting business. I'm registered as a PE in 11 states and have an NCEES Record. Current committee service includes the International Institute of Ammonia Refrigeration (Standards-CM and Government Relations-VM) and the American Society of Heating, Refrigerating and Air-Conditioning Engineers (Std 15, TC 10.1, TC 10.3 and TC 10.5; VM on all). I have revised portions of chapter 2 in the 2014 and 2018 editions of the ASHRAE Refrigeration Handbook and am completing calculations of CO2 piping capacities in chapter 3....

Justin Hall, MAS, PE Hall Engineering Group, Ltd

Little Rock, Arkansas
Engineering, Construction Defects - Civil Engineering, mechanical engineering, engineering, construction, construction fault, forensic engineering, structural failure, structural inspection. Licensed in AR, TX, OK, MO, KS, MS.
...With over 20 years of experience in engineering and forensic consulting, design, construction assessments, international codes and research, Justin Hall, PE has provided clients with structural analysis and design, condition assessment, damage investigations, failure analysis, construction consulting & management, and expert testimony. States include Arkansas, Missouri, Oklahoma, Texas, Tennessee, Louisiana and Mississippi....

Victor L. Mandoff, MD, FASA

Little Rock, Arkansas
Anesthesiology, Critical Care Medicine - Acute Pain, Regional, Airway injuries, Difficult Airways, Critical Care, ACLS, BLS, Codes, Trauma Emergencies, Drug errors, Narcotics, Neuromuscular Blockers, Propofol Pharma, Invasive-catheters, OR fires, Simulation, Position/Nerve injuries, Sedation, Recall, Vents, Outpatient and Non-OR surgery
...The FASA designation is the "highest acknowledgment that recognizes years of dedication to exceptional education, leadership and commitment to the specialty" as per American Society of Anesthesiologists website. I am also Critical Care Fellowship trained at the Cleveland Clinic Medical Foundation and was Critical Care Board Certified and practiced Critical Care Medicine 2006 to about 2016. UAMS provides care to the highest acuity patients from the state and surrounding areas. It is the only level one trauma center in Arkansas and the only one that does liver transplantations. I provide anesthesia for a variety of cases like liver transplants, kidney transplants, vascular surgery. thoracic, obstetric, neurosurgical, ENT, outpatient, GI, radiology, Cath Lab, Electroconvulsive therapy, etc. I serve or have served on many committees such as Director of Liver Transplantations, Maintenance of Certification Assessment (MOCA) Simulation Course Director, Code Blue, Rapid response Teams....

Janet G Attard, RN IV, RNC-MNN, CLNC, MBA, 1L The Legal Nurse Consultant Group

Danville , California
Neonatal - Perinatal Medicine, Obstetrics & Gynecology - High Risk Obstetric Care in the areas of L&D, Antepartum, Triage, Post Partum, and NICU. Legal Nurse Consulting, Standard of Care, Scope of Practice, Chain of Command, Communication, Team Work, Collaboration, Risk Management, Quality Assurance, Performance Improvement, Administration Responsibility
...Jan is present and in active practice with High Risk Hemorrhage, Hypertensive Crisis, and Infant Code scenarios to save lives of mothers and infants on a daily basis. Scope of Practice and Standard of Care for Infant, NICU, and Maternal specialty areas spell out how the care to the patient is performed. Jan drafts concise and to the point Summary Reports including Chronology, Breach of Duty of Care specific to the Specialized Nurse Profession. Confidential Reports are designed for the firm pre- deposition. We provide case review for The California Board of Registered Nursing.

MARTIN M BALABAN, PhD, PE AR TECH

Encino, California
Accident Reconstruction, Safety - Vehicle collisions, Premises liability including slip/trip & fall, Safety, Code Compliance, Construction & Industrial Accidents, Failure Analysis, Human Factors, Biomechanics, Mechanical Engineering, OSHA, ADA compliance, Products Liability, Criminal, Licensed Safety Engineer by State of California
...Premises Liability: Code Compliance, Slip, trip, floor friction testing, stairway & ramp accidents, glass injuries, guardrails; illumination issues; manual & electronic gates, ladders, door closing mechanisms, falling objects, structural failures. Occupancies include single- and multi-family residences, retail stores, office buildings, garages, sidewalks, parks and other public access. Industrial & Construction accidents: Walking-working surfaces including ramps, hoisting & conveying, powered lifts, work platforms, forklifts, construction vehicles, materials handling & storage, machine guarding, ladders, scaffolding, trenching & shoring, Cal-OSHA compliance, lockout/tagout, IIPP analysis, human factors & ergonomics issues. Products Liability: Liability regarding design, manufacturing, maintenance, failure to warn....

David Chapman

San Jose, California
Intellectual Property, Electronics - Software, Electronic Design Automation, EDA, Semiconductor, GDS, GDSII, OASIS
David Chapman is an experienced software developer who has written over 1,300,000 lines of code in C/C++ and other languages. He has written software for many areas of semiconductor electronic design automation: mask data preparation, design rule checking, circuit extraction, circuit delay characterization, logic synthesis, physical synthesis, placement, routing, Intellectual Property identification, and transistor level layout generation. He has over 20 years of consulting experience and was the chair of the Consultants' Network of Silicon Valley in 2018-2019. He has 12 U.S. patents granted. His expert witness work to date has focused on discovery/analysis of semiconductor layouts (GDS/GDSII, OASIS), especially for patent infringement. His sharp eyes plus his understanding of semiconductor processing and design tools mean that if it's there, he can find it.

Gary K Dempster, FAIA Stir Architecture

Los Angeles, California
Architecture, Construction - Professional Standard of Care, Construction Documents Analysis, Architectural Design and Coordination, Building Code Analysis, Scope of Work Definition, Change Order Analysis, Construction Administration, Architectural Mediation
For the past 32 years, I have been a hands-on partner in charge of projects. I am actively involved with the owners, general contractors, critical trade sub-contractors and all government authorities having jurisdiction. I prepare proposals, craft contracts, oversee the creation of the contract documents and have primary responsibility during the Construction Administration phase. I am licensed in 7 states and have delivered projects in 11 states and 3 countries ranging in construction costs from $2,000,000 to $500,000,000,

Don Gottfeld Gottfeld Architects, Inc.

Long Beach, California
Architecture, Construction - Real Estate,Development,Construction Defects & Failures,Design Defects, Landlord/Tenant,Property Management,Slip, Trip & Fall,Parking Lots,Building Codes,Building Department,Planning/Zoning,City Inspections,Leases,Construction Drawings & Details,Owner/Architect Disputes, Owner/Contractor Disputes
...He has designed, developed, and managed multiple residential and commercial properties, responsible for the acquisition and city approvals to site improvements, general contracting/construction and ongoing property management. Mr. Gottfeld is a licensed Architect, a member of the American Institute of Architects (AIA) and is certified by the National Council of Architectural Registration Boards (NCARB). He is a licensed General Contractor and a licensed Real Estate Broker. He is certified by the California Governor’s Office of Emergency Services (OES), Disaster Services Safety Assessment Inspector. Licensed Architect State of California #C23939 (March 1993-Present) Licensed Architect State of Hawaii #9568 (Oct. 1998-April 2020) NCARB Certification #45674 (Jan. 1995-Present) “National Council of Architectural Registration Boards” recognizes and qualifies reciprocal Architect registration throughout the United States and signifies the profession’s highest standard of competence....

Bradley C. Hammerstrom, AIA, NCARB The Diehl Group Architects, Inc.

Encinitas, California
Construction Defects, Architecture - Forensic Architecture, Destructive Testing, Site Inspections, Construction Defects, Building Envelope, Roofing, Fenestration, Waterproofing, Exterior Claddings, Construction Drawings, Contract Administration, Slip and Fall, Building Code, Peer Review, Quality Assurance, Testimony.
...Experience includes field investigations, water intrusion analysis, construction installation sequencing, code analysis, development of repair solutions, trial preparation and expert witness testimony. Projects include residential, commercial, and high rise in California, Nevada, Arizona, Colorado and Texas (licensed in 5 states). Experience also includes traditional architectural services for projects involving repair or reconstruction: architectural design, production of construction documents and contract administration. Experience includes consulting for architects and developers to provide peer-review of drawings, quality assurance site observations, evaluation of in-progress construction for conformance to the construction drawings and specifications and workmanship standards. AIA - American Institute of Architects NCARB - National council of Architectural Registration Boards Licensed in the Following States: California (Primary), Arizona, Colorado, Nevada, Texas

Carl H. Josephson, PE, SE Josephson-Werdowatz & Associates, Inc.

San Diego, California
Structural Engineering, Engineering - Wood, masonry, steel, concrete structures. Construction defect, insurance litigation, professional liability claims. Seismic/wind design, code review, standard of care analysis. Also foundations, underpinning, retaining walls, and tie-backs. Extensive graphics and animations capabilities.
Josephson-Werdowatz & Associates (JWA), founded in 1988 and with licenses in thirty states, has provided structural design and construction defect investigations/evaluations across the United States and abroad. Structural evaluations included wood, masonry, steel, and concrete structures, with particular emphasis on seismic and wind design. JWA has experience working with specialty materials such as acrylic, aluminum, and glass as well. Evaluations also include code review and analysis, and standard of care analysis. JWA has extensive experience with geotechnical structures such as special foundations, underpinning, retaining walls, tie-backs, and soil nails, among others. JWA strives for a reasoned, accurate, and practical solution to structural engineering problems and deficiencies. Principal Structural Engineers Carl H. Josephson, PE, SE; Dan R. Werdowatz PE, SE; and Stephen P....

Ron D Kammeyer, CLARB, BS, RLA Kammeyer & Associates, Inc.

Corona, California
Landscape Design, Construction Defects - Landscape Architecture, Personal Injury, Landscape Standard of Care, Parks & Recreation / Sports Facilities, A.D.A. Design and Access, Landscape Maintenance, Landscape Construction, Irrigation, Water & Drainage, Arboriculture, Horticulture, Code Violations
Ron Kammeyer has decades of professional Landscape Architectural experience in research, design, construction documents, construction, observation, and maintenance. His award winning company, Kammeyer & Associates, Inc., established in 1966, was awarded the ASLA "Centennial Medallion" (only awarded every 100 years). Ron Kammeyer is professionally licensed in California, Nevada, Hawaii, and Canada, and has current projects under design or construction. He holds a BS degree in Landscape Architecture and has served over the years as a guest professor at UCLA. Ron's experience since licensure in 1982 results in high quality standard practice of the industry allowing the involved parties to accurately assess the loss, advance successful claims, and/or mitigate liability. Kammeyer was also an author of WUCOLS (Water Use Classification of Landscape Species) which was adopted by the State of California Department of Water Resources to designate the water use of thousands of plant species....

Larry Steven Londre, MBA, Londre Marketing Consultants, LLC / USC / Pepperdine/ California State University, Northridge

Los Angeles, California
Marketing, Advertising - Marketing, Sales, Advertising, Ads, Promotion, Misleading, Deceptive Ads, Unfair Advertising, Business Practices, Intellectual Property, Patents, Deceptive Promotion, Trade Dress, Unfair Competition, Marketing Intelligence, Partners, Copyrights, Forensic Marketing, Web, Sales, Global, Clients
...Cases: Marketing; Advertising; Ads; breach of contract; business strategies, practices; business and professions code compliance and violations; unfair competition, contracts, sponsorships; deceptive, false advertising; media; intellectual property; patents; usage of models; advertising agencies; trade secrets; partner business practices; unfair advertising; deceptive advertising; violations of Lanham Act; unjust enrichment; trademarks at issue; comparative advertising/promotion; licensing; packaging; the value of advertising and media campaigns. I have been deposed, testified in court and arbitration: 54 times. Cases have included contracts between partners, directors, advertising agencies, clients, advertisers, suppliers, distributors, production firms and media....

Fred B. Lott, AIA, ARA, CSI Fred Lott Architect

California
Architecture, Construction Defects - Architect & Engineer Negligence, Construction Defects, Fraudulent Change Orders, Construction License Agreement, Antitrust Complaint, Standard of Care Responsibility & Compliance, Warehouse Thermal Comfort, Bid Steering, Treachery & Self-Dealing Related to Professional Practice Industry Standards
...Expert Witness & Dispute Resolution 34 years Registered Architect 44 years Construction Executive 28 years Owner Representative 24 years Fred leverages his in-depth experience of leading cross-discipline teams of design & engineering professionals and construction management teams when presenting detailed opinions and support information in an understandable way. Fred’s work has included community boards, governing agencies, investors, General Services Administration - Offices of the Inspector General, FBI, multiple state courts (including Indiana, Illinois, California, Georgia, Florida, and New York), the New York County District Attorney’s Office (Labor Racketeering Unit, Construction Industry Strike Force), the New York City Office of Administrative Trials & Hearings, and the City of New York Police Department (District Attorney’s Office Squad)....

Timothy P McCormick, PE McCormick & Associates, Inc.

Torrance, California
Building Inspection, Construction Defects - Building Codes Compliance, ADA/FHA Compliance
Expert review of construction drawings and inspection of buildings for compliance with applicable codes, regulations and practice standards. Registered civil engineer and licensed general contractor in the State of California. Certified as a Plans Examiner and Building Official by the International Code Council. Specialized knowledge in accessibility design and construction requirements mandated under the Federal Fair Housing Act, Americans with Disabilities Act and California Building Code. Licensed as a Certified Access Specialist (CASp) by the California Division of the State Architect.

Mark Mooring, CPP, CHPA

Ventura, California
Security, Premises Liability - Security Training, Security Deployment, Use of Force, Hospital Security, Security Policies and Procedures, Active Shooter
...(1998-2006) Completely re-designed and implemented a comprehensive security program, which includes all facets of Security Plan Development, Staff Development, Policies, Training, Recruitment, Personnel Management and daily security operations, associated with a large County Hospital. Proper Authorities LLC - Founder (1993-Present) Crime Prevention, Loss Prevention, Safety/Security Assessments, Workplace Violence Prevention, Personal Safety, Sexual Harassment, Threat Assessments and Managing Assaultive Behavior. Developed comprehensive Use of Force Policies and Programs. Developed and delivered Workplace Violence Programs. Services also include, confidential Investigations involving use of force, theft, stalking, harassment, fraud, hazardous conditions, threats, and drug use. Developed and delivered Security Officer specific training, including tactics and firearm safety....

Tracy Myers, AIA Myers Consulting

California
Architecture, Construction Defects - Standard of care, general construction, personal injury, slip and fall, stairs, accessibility, ADA, construction, defect analysis, roofing, waterproofing, fenestration, building enclosure, building envelope, accident, contracts, architect, general contractor, NCARB, RRO, trip and fall, architecture
Tracy Myers is an architect and general contractor with 31 years of broad experience in architectural design, project management, construction administration, general construction, forensics, and property loss consulting. She specializes in expert witness testimony related to architectural and general construction issues, personal injury defect and accident investigation, building enclosure investigation and repair including waterproofing, roofing and fenestration, forensic architecture, litigation support, property loss evaluation, code upgrade review, peer review and quality assurance services. Ms. Myers has worked in the forensic field for over 20 years and has provided consulting expertise on a variety of project types including single and multi-family residential, industrial, health care, hospitality, office, commercial, educational, and retail....

David E. Pilcher, CPCU, ARM, AIC, AAI David E. Pilcher, CPCU, ARM, AIC, AAI

Monrovia, California
Insurance, Risk Management - Workers Compensation, General Liability insurance, Personal and Commercial Lines, Errors and Omissions Casualty Claims, Bad Faith, Risk Management / Loss Control, Coverage and/or Contractual Disputes, Employer Practices Liability, Wage and Hour Disputes, and other Casualty issues.
...I have significant experience in litigated casualty claims case management combined with a thorough knowledge of tort liability and common law principles, workers' compensation law and the Labor Code, claims practices, underwriting, and sound risk management and loss control procedures. I have qualified as an expert witness before the Superior Court of California and the United States District Court, Central District of California, and hold several recognized professional designations, an active CA Broker/Agent and Life Agent license, and a CA Self Insurance Administrators Certificate.

Matthew A Reynolds, PE Rowley and Reynolds Forensic Engineering, Inc.

Palos Verdes, California
Aquatics Safety, Construction - Drownings, Swimming Pool and Aquatic Related Accidents, Aquatic Accident Reconstruction, Swimming Pools, Spas / Hot Tubs, Waterslides / Aquatic Amusement Rides, Swimming Pool Design / Construction, Swimming Pool Operation / Maintenance, Swimming Pool Equipment, Aquatic Codes and Standard of Care
...He has extensive experience designing and overseeing the construction administration of swimming pools and investigating the spectrum of mechanical system and structural failures. Reynolds has designed more than 200 major commercial and residential swimming pools and spas nationwide. In obtaining his Bachelor of Science in Civil Engineering and through his professional experience designing swimming pools and investigating structural failures, Reynolds is accustomed to reviewing the often-complex seismic and geotechnical issues that play a major role in swimming pool projects. As a youth, he swam competitively and played water polo through college, which he later coached at both the high school and collegiate level. He trained as a junior lifeguard then qualified and served as a lifeguard. He is also an experienced swim instructor and aquatic sport camp counselor. He entered the industry after graduating from Loyola Marymount University....

Taylor A. Russell, P.E., CAP, CFEI Engineering Design & Testing Corp.

Concord, California
Electrical Engineering, Industrial Design - Industrial Automation, Building Automation, Power Systems, Electrical Design & Construction, Battery Technology, Power Electronics, Control Systems, Manufacturing, Water Treatment, Wastewater Treatment, Arc Flash, Fires and Explosions, Code Compliance
Forensic Electrical Engineer with over a decade of experience in the design, construction, testing, and commissioning of power and automation systems for utilities, industry, and commercial applications. Expert in determining the cause of electrical and control system failures, electrical fires, arc-flash incidents, battery fires, and utility power systems. Licensed in most western states. Certified Automation Professional (ISA), Certified Fire & Explosion Investigator (NAFI).

Clark Stoner, PE, PLS Bear Flag Engineering Inc

Sonoma, California
Civil Engineering, Land Surveying - Civil Engineer, Land Surveyor, Geomatics Engineer, Boundary Disputes, Easements, LiDAR, Laser Scanning, UAV, Drone, Aerial Photogrammetry, Change Detection, Aerial Photo Analysis, Floodplains, Flooding, Hydraulics, Storm Drains, Sanitary Sewers, Water and Wastewater Treatment, Landslides, Wildfires
...His experience ranges from the design, construction and operation of large scale water and wastewater infrastructure facilities to the design and construction of amusement theme parks, subdivisions and residential, commercial and hospitality projects. He also has extensive experience as technical expert in litigation support matters involving massive flooding events, storm drain and sanitary sewer systems, landslides, land subsidence, change detection, code compliance, construction defect, origin and cause investigations, failure analysis, boundary and easement disputes, and standard of care. He has testified as an expert witness in California and Nevada on a range of issues. Mr. Stoner has also assisted consulting and legal teams to develop the macro perspective on litigation support matters through use of remote sensing techniques, such as aerial and terrestrial LiDAR, 3D laser scanning, multi-spectral imaging and photogrammetry to gather additional facts otherwise undetected....

Barry Taheri California Consultants

Long Beach, California
Construction Defects, Construction Engineering - Waterproofing, Building Envelope, Windows and Doors, Leak Investigation, building Enclosure, Below Grade, Above Grade, Roof, Planters, Construction Standard Of Care, Water Damage
...Over the past 24 years, he has completed over 5,000 forensic projects and is a designated industry expert for the California Contractors State License Bureau (CSLB) Qualifications, experience and accreditations are as follows; Firm-California Consultants: • Designated industry expert for the state of California (CSLB) • Over 25 years’ experience in Forensics, Weatherization, Field Testing. • Building Envelope member, of the Los Angeles Chapter of the BEC. • DuPont Envelope Certification number: DWSRC 1082 • State of California Contractor’s License: B 904491 • Certified Water Testing with equipment calibrated annually. • Certified in Thermographic imaging. • Technical Writer for Code Programs (Lessons from prior building cycles) • Consultant and Industry Expert - 30 years of Experience in Commercial and Residential Construction. • Experience in Forensic Investigation and Analysis of Construction Defects: Site Inspections, Destructive Testing, Issues Analysis and Cost of Repair. • Litigation...

Joshua Weiner, NABCEP SepiSolar, Inc

Fremont, California
Energy, Architecture - Solar,PV,Photovoltaics,Energy Storage,Batteries,Construction,Electric Utility,Industry,Business,Standards,Requirements,Intellectual Property,Project Development,Planning,Independent Engineering,Owners Representative,Construction Management,Electrical Engineering,Asset Management,Contracts
...Specific areas of expertise, listed below, include energy technologies, markets, policy, finance, project development, planning and execution, project management, and codes and standards. Weiner is adept at unpacking complex topics into simple language that all parties can understand. Since 2007, Weiner is a certified member of the North American Board of Certified Energy Practitioners (NABCEP) in good standing. Weiner has also taught advanced solar system design and project management at UC Berkeley....

Eric Welch Bramson Welch & Associates, Inc.

Berkeley, California
Electrical Engineering, Software Engineering - Smart Phone Accessories, Bluetooth, Wireless, USB, Embedded Systems, Forensic Engineering, Firmware, Source Code, Design Review
...I have performed software and design reviews and done forensic engineering. Sample projects include handheld wireless medical sensor; 150 MSPS automotive sensor interface; Smart Phone interface for survey grade GPS device; the secure, wireless communication subsystem for a line of consumer medical products.

Randy A Winters MatrixHCI, LLC

California
Software Engineering, Computers - Cybersecurity, Software Architecture, Artificial Intelligence, Cryptocurrency / Blockchain, Speech & Face Recognition, ESI Protocol, Social Media Forensics, Biometric Identifiers, Code Review, Patent Infringement ,Trade Secret, IPR, PTAB, Claim Analysis, Forensic Data Extraction, BIPA
...- In addition to his blockchain development experience, he designed the first cryptocurrency arbitrage system....

Michael Fiebig, RA, AIA, NCARB, LEED GA, CFPS, CEP Fiebig Architecture

Highlands Ranch, Colorado
Construction Defects, Premises Liability - Architecture, Construction, Construction Defect, Fire Protection, Fire Suppression, Fire-Resistive Assemblies, Residential Construction, Commercial Construction, Building Codes, Premises Liability, Slip & Fall, Trip & Fall.
Registered architect with NCARB certificate in twenty states (licensed in more states than are listed in this directory), with an active design and forensic practice. As a forensic architect, his experience includes among other things, performing analysis of standard of care in building design and construction projects; performing analyses of building systems including roofing systems, window and door systems, exterior wall cladding systems, waterproofing and foundation systems, with a specialization in fire-resistive assemblies and active fire-protection systems. His experience includes premises liability investigation and analysis of accident sites relating to the built environment, both indoors and outdoors. As a design architect, his practice includes traditional architectural practice including building design, building code analysis & application, and services during construction....

Fred B. Lott, AIA, ARA, CSI Fred Lott Architect

Westport, Connecticut
Architecture, Construction Defects - Architect & Engineer Negligence, Construction Defects, Fraudulent Change Orders, Construction License Agreement, Antitrust Complaint, Standard of Care Responsibility & Compliance, Warehouse Thermal Comfort, Bid Steering, Treachery & Self-Dealing Related to Professional Practice Industry Standards
...Expert Witness & Dispute Resolution 34 years Registered Architect 44 years Construction Executive 28 years Owner Representative 24 years Fred leverages his in-depth experience of leading cross-discipline teams of design & engineering professionals and construction management teams when presenting detailed opinions and support information in an understandable way. Fred’s work has included community boards, governing agencies, investors, General Services Administration - Offices of the Inspector General, FBI, multiple state courts (including Indiana, Illinois, California, Georgia, Florida, and New York), the New York County District Attorney’s Office (Labor Racketeering Unit, Construction Industry Strike Force), the New York City Office of Administrative Trials & Hearings, and the City of New York Police Department (District Attorney’s Office Squad)....

Brian K Bramel, SE, PE, Ph.D. Bramel Engineering

District Of Columbia
Structural Engineering, Construction Defects - Construction, construction site safety, concrete, open web joist, light gage steel, underpinning, mechanical engineering, product defects, failure analysis, finite elements, design build
...Bramel has over 30 years of broad Engineering experience in all aspects of the construction process: from design through construction and service. Dr. Bramel has effectively served as an Expert Witness and a litigation advisor on hundreds of cases in the past 10 years. He has advised in Construction Defect, Building and Material Failures, Product Liability, Personal Injury, Construction Work Site Injuries, Multi-Employer Worksite Matters, as well as building code compliance and insurance claims throughout the mid-Atlantic region. His expertise in Civil, Mechanical, and Structural Engineering allows a broad perspective of potential matters beyond the traditional Engineering solutions. Dr. Bramel is a practicing Licensed Professional Engineer in Virginia, Maryland, West Virginia, Pennsylvania, Ohio, New York, and Delaware, a practicing Licensed Structural Engineer in Washington, D.C., and a Model PE NCEES record holder....

Matthew Furlong, CBC, RBC Först Consulting Group

District Of Columbia
Construction Defects, Construction - Forensic investigation, building pathology, failure analysis, technical reporting, construction claims, litigation support, insurance, building code, EIFs, stucco, building envelope, facades, rainscreen, infrared, moisture, structural capability, energy conservation, contract analysis.
...Furlong has 21 years of experience with construction, project coordination and design, remodeling, and field inspections of building systems for residential, and commercial low and high-rise properties. He has successfully completed more than 600 unique and custom projects while as a general contractor. His builder background experience ranges from high-end new custom home construction, interior renovations and additions, to green building and energy efficient homes, historical renovations, timber-framing, and creating elaborate custom interiors in prestigious estate-sized homes. This experience gives Mr. Furlong the unique qualifications to testify as an expert in construction matters. As a professional consultant, Mr. Furlong provides services in the forensic investigation field related to construction defects, Building Code compliance, contract review and analysis, construction delay analysis and investigation....

Richard S. Barrow, PE, SI Barrow Engineering, LLC

Estero, Florida
Structural Engineering, Building Inspection - Structural failures, structural engineering, Structural design, design errors, structural inspections, building collapse, building codes, structural repairs, forensic engineering, special inspector, special inspection, threshold inspection
...Barrow has performed numerous forensic investigations involving structural failures, design deficiencies, faulty construction, construction pay applications, failure to disclose defects, grading issues, cladding failures, roof damage, site plans, pool leaks, water intrusion, fire, wind, subsidence, and vehicular impact. Design of shoring, and other remedial actions have been provided as part of forensic projects where there are conditions that may become unsafe or need repair. Mr. Barrow is experienced in insurance claim work, litigation, and testimony involving legal issues. He has testified under oath in court and in depositions and has presented at mediation and arbitration hearings. Prior to Barrow Engineering, LLC, Mr. Barrow was the president and founder of Liebl & Barrow Engineering, Inc. (“LBE”) located in Fort Myers, FL....

Nick M Bradford, PhD PE SE SI TSG Engineering, Inc.

Tampa, Florida
Structural Engineering, Construction Engineering - Structural Failure / Collapse, Structural design, Structural Analysis, Structural Inspections, Building Code Analysis, Construction Defects, Forensic Engineering, Hurricane Engineering, Failure Analysis, Wind Engineering, Flood Engineering
...In the area of forensic engineering, we provide structural engineering failure investigations, feasibility assessments, structural failure/collapse analysis reports, and Building Code assessments. Further, we provide construction documents for facilitating rehabilitation/repairs of damaged structures. We have significant experience with fire, wind, vehicular impact, subsidence, water, insects, improper design, and faulty construction. Dr. Bradford is a certified Neutral Evaluator for Sinkhole disputes in the State of Florida. Dr. Bradford has worked on approximately 250 projects involving insurance claims. He has also testified as an expert witness in court, by deposition, in mediation, and in non-binding arbitration. Dr. Bradford is a licensed Professional Engineer in 8 states and a licensed Special Inspector (Threshold Inspector) in the State of Florida. He has been the Special Inspector for a variety of structures involving a variety of structural systems.

Gregory J Cahanin, CP Cahanin Fire & Code Consulting

St. Petersburg, Florida
Fire, Failure Analysis - Kitchen Fire Suppression Systems, Fire Sprinkler System Failure, CPVC sprinkler pipe failure, Fire Walls, Life Safety Egress, Fire Codes, Fire Hazard Analysis, Explosion Analysis and Cause, Fire Alarms, Walking Surface Slip Trip & Fall, Fire Origin and Cause Investigation, Fire Construction Defects
...Fire and Building Code construction defect findings are supported by 45+ years of working with national codes and standards. Gregory Cahanin also performs code compliance and development for property owners and manufacturers. Working on staff at the National Fire Protection Association, Quincy, MA, Mr. Cahanin was a Senior Life Safety Engineer. Primary responsibilities were in support of Life Safety Code development and education. He was staff liaison for building construction standards and the Fire Prevention Code. Special project work included support of the International Division of NFPA in a survey of fire protection for all oil production facilities of LaGoven SA in Venezuela; an evaluation of the existing airport terminal in Rio De Janeiro, Brazil; and a code comparison study for the National Institute of Building Sciences. Multiple fatality fire investigations while with NFPA were performed with findings nationally published and peer reviewed. Mr....

Rossana Diaz, PE, SI m2e Consulting Engineers

Miami, Florida
Structural Engineering, Failure Analysis
...Diaz has more than 10 years of experience providing structural engineering design, construction administration, and forensic services to private-sector clients on a wide range of projects. As a forensic engineer, Rossana investigates structural failures, building construction defects, and code compliance on behalf of attorneys, and insurance companies. Rossana’s design portfolio includes development, from conceptual design and plan preparation through construction and final inspection. Her areas of expertise include building castin-place concrete, steel, masonry, and timber design for commercial and residential structures, educational and hospitality facilities, marinas, and industrial plants.

Curtis E Falany, PE J.B. Shepherd & Co., Inc.

Plant City, Florida
Electrical Engineering, Construction Defects - Electrical Contact,Shock,Electricity,Electrocution,Construction Defect,Construction Dispute,Fire of Electrical Origin,Explosion, Wildland Fire of Electrical Origin,Failure,Lightning,Electric Utility,Transmission,Distribution,Forensic Engineer,Expert,Witness,Opinion,Testimony,NEC,NESC
...Previously, he was the CEO of an electrical design-build firm and a principal in a consortium of companies serving the electrical, computer, and communications industries worldwide. He has served as a member of the Florida Electrical Contractors Licensing Board and as the author of the Hillsborough County Florida Electrical Code. Curtis is Board Certified as a Forensic Engineer. He has assisted clients in the investigation and resolution of more than 600 cases in State and Federal Courts both in the US and overseas.

Michael Fiebig, RA, AIA, NCARB, LEED GA, CFPS, CEP Fiebig Architecture

Florida
Construction Defects, Premises Liability - Architecture, Construction, Construction Defect, Fire Protection, Fire Suppression, Fire-Resistive Assemblies, Residential Construction, Commercial Construction, Building Codes, Premises Liability, Slip & Fall, Trip & Fall.
Registered architect with NCARB certificate in twenty states (licensed in more states than are listed in this directory), with an active design and forensic practice. As a forensic architect, his experience includes among other things, performing analysis of standard of care in building design and construction projects; performing analyses of building systems including roofing systems, window and door systems, exterior wall cladding systems, waterproofing and foundation systems, with a specialization in fire-resistive assemblies and active fire-protection systems. His experience includes premises liability investigation and analysis of accident sites relating to the built environment, both indoors and outdoors. As a design architect, his practice includes traditional architectural practice including building design, building code analysis & application, and services during construction....

Clinton J. Ford, M. Sc. ACA, CGC, CIE, CMR, CRMI Advanced Building Consultants

Alachua, Florida
Construction, Environmental - Appraisal & Valuation, Arbitration/Mediation, Building Inspection, Construction, Construction Defects, Environmental, Indoor Air Quality, Mold, OSHA, Premises Liability, Safety, Slip Trip & Fall
...Using up-to-date technology combined with his elite knowledge of building codes, standards, and statutes, Ford is consistently able to present analysis and witnessing that can be described as nothing but expert. Ford’s additional services and certifications are displayed below: Insurance: ACA - All Lines Independent Claims Adjuster Florida 520 Licenses #087209 since 2004 Florida Unaffiliated General Lines Property & Casualty Insurance Agent 2-20 License #A087209 since 2011 National Flood Insurance Program Claims Adjuster – Cert....

Scott Harvey-Lewis, PE, LEED AP Building Mavens

Palm Beach Gardens, Florida
Structural Engineering, Construction Defects - Building Inspection, construction, civil engineering, milestone inspections, structural integrity inspections, Building Enclosures, Exterior Walls and Cladding Systems, Waterproofing Systems, Roofing Systems, Water Intrusion Investigations
...Harvey-Lewis has more than 17 years of experience providing structural engineering design, construction administration, and forensic services to public and private-sector clients on various projects. As a forensic engineer, Scott investigates structural failures, building construction defects, and code compliance on behalf of attorneys, owners, developers, and insurance companies. Scott’s design portfolio includes significant phases of project development, from conceptual design and plan preparation through construction and final inspection. His expertise includes building envelope systems, cast-in-place concrete, steel, masonry, and timber design for commercial and residential structures, telecommunication and educational facilities, marinas, industrial plants, warehouses, storage and containment, and land development.

William Henry, PhD, NCARB RGA Design Forensics LLC

Tampa, Florida
Premises Liability, Disaster Recovery - Accident Investigation, Building Codes, ADA, Accessibility, Slip Trip & Fall, Forensic, Architecture, Engineering, E&O, Errors and Omissions, Construction Defects, Mold, Cruise Ship, Maintenance, Building Inspection, Insurance Claims, Disaster Recovery, Failure Analysis, Property Insurance
...Henry, our lead expert, utilizes three components in his case development: (1) a detailed timeline, (2) an analysis of the governing codes and documentation, and (3) the application of the facts to those governing codes. His reports and testimony are presented in a simple, clear manner that is easily understood. This approach has had a proven impact on the outcomes of past matters, whether in settlement, mediation, arbitration, or at trial. RGA Design Forensics’ main areas of expertise are premises liability, property insurance litigation, and architectural errors and omissions (E&O) claims. Premises Liability - Whether a slip trip & fall or some other incident, RGA works with both plaintiff and defense counsels to determine adherence to or deviation from governing codes, standards, and guidelines around the site. This information is vital in determining causality in a case....

Paul L. Johnson Gryphon Consulting

Holiday, Florida
Construction Defects, Construction - Residential, commercial, leaks, tenant fit-outs, kitchens, baths, remodels, construction related slip-fall & personal injury, historic buildings, restaurants, roofs, siding, critical path, luxury construction, high-end construction, wine cellars, cabinetry, Schluter Systems, tile, stone, masonry
...I work to stay current on construction processes, materials, technique's, industry changes and codes through construction of investment properties. Areas of expertise include, but are not limited to: • Construction Defects • Personal Injury resulting from Construction Defects • Cabinetry/Trim Defects • Interior Finish Defects • Exterior Finish Defects • Water Intrusion Issues • Window & Door Defects • Framing Defects • Tile & Stone Defects • ADA, IRC and IBC CodesDesign/build Process • Critical Path Scheduling

Sanford Kaminsky, AIA, NCARB m2e Consulting Engineers

Miami - Coral Gables, Florida
Architecture, Construction Defects - Standard of Care, Failure Analysis, Construction Documents, Defect, Change Order, Building, Design, Condominium, Hospitality, Casino, gaming, Code Compliance, Contract Document, Field Management, Contract Administration, Commercial, Highrise, Retail, Hotel, Condo-Hotel, Institutional and Industrial.
...Multi-Billion Dollars of Experience Both Designed and Constructed. Skills Include All Facets of Architectural Practice, Including Condominium Defect Mitigation That Would Dismantle A Class Action Lawsuit. Worldwide Project Experience Includes Retail, Office, Hotel, Institutional, Aerospace and Mixed-Use. Deposed On Standard Of Care, AHCA Regulations Regarding The Design Of A Class III Operating Room, And A Wrongful Death Based On My OSHA Certification. 40+ years experience in construction defect litigation support and expert witness services for both plaintiff and defense attorneys. Experienced in field investigations, Failure Analysis water intrusion analysis, specialty construction methods, development of repair methodologies and de-watering techniques, trial preparation and expert witness testimony. Projects include commercial and high rise in California, Nevada, and Florida....

Fred B. Lott, AIA, ARA, CSI Fred Lott Architect

Florida
Architecture, Construction Defects - Architect & Engineer Negligence, Construction Defects, Fraudulent Change Orders, Construction License Agreement, Antitrust Complaint, Standard of Care Responsibility & Compliance, Warehouse Thermal Comfort, Bid Steering, Treachery & Self-Dealing Related to Professional Practice Industry Standards
...Expert Witness & Dispute Resolution 34 years Registered Architect 44 years Construction Executive 28 years Owner Representative 24 years Fred leverages his in-depth experience of leading cross-discipline teams of design & engineering professionals and construction management teams when presenting detailed opinions and support information in an understandable way. Fred’s work has included community boards, governing agencies, investors, General Services Administration - Offices of the Inspector General, FBI, multiple state courts (including Indiana, Illinois, California, Georgia, Florida, and New York), the New York County District Attorney’s Office (Labor Racketeering Unit, Construction Industry Strike Force), the New York City Office of Administrative Trials & Hearings, and the City of New York Police Department (District Attorney’s Office Squad)....

Vladimir K. Markoski, PE M2E Consulting Engineers

Miami, Florida
Engineering, Mechanical Engineering - HVAC, MEP Design, Fire Protection, Life Safety, NFPA codes, UL standards, LEED, Plumbing Systems
Forensic Engineering and Law class lecturer, University of Miami, School of Civil, Architectural, and Environmental Engineering This course is designed to provide background and working knowledge of how forensic engineering projects are initiated and managed from engineer’s and attorney’s perspectives. Various elements required in a forensic investigation project from condition assessment to expert report preparation and expert testimony are covered. The role of the forensic engineering expert is explained from the view of the engineer and attorney.

Stephen B McWilliam, ABR,CRB,CRS,GRI Florida State Realty Group, Inc

Fort Lauderdale, Florida
Real Estate, Financial - Florida REALTORS®/Florida BAR (f/k/a FAR/BAR) Purchase Contracts, REALTOR® Code of Ethics, Procuring cause, Residential and Commerical real estate transactions, REALTOR® Standard of Care, REALTORS® negligence, fraud, malpractice claims, MLS (Multiple Listing System) Best Practices and Policies.
...Stephen has earned four of the most prestigious real estate professional designations offered by the National Association of REALTORS®, ABR (Accredited Buyer's Representative), CRB (Certified Real Estate Brokerage Manager), CRS (Certified Residential Specialist) and GRI (Graduate of the REALTOR® Institute). Stephen is a Florida licensed real estate broker, school instructor, and mortgage loan originator. Stephen served as the elected 2012 president of one of the largest REALTOR® associations in the USA. Additionally, Stephen served for 10 years on the Florida REALTORS®Board of Directors and 7 years on the National Association Board of REALTORS®. Stephen has served and been chairman of numerous committees within his local REALTOR® association and at both the state and national levels. Stephen continues to serve his local association as an ombudsman working to resolve disputes and as a hearing panel chair for both arbitration and ethics hearings....

Tracy Myers, AIA Myers Consulting

Altamonte Springs, Florida
Architecture, Construction Defects - Standard of care, general construction, personal injury, slip and fall, stairs, accessibility, ADA, construction, defect analysis, roofing, waterproofing, fenestration, building enclosure, building envelope, accident, contracts, architect, general contractor, NCARB, RRO, trip and fall, architecture
Tracy Myers is an architect and general contractor with 31 years of broad experience in architectural design, project management, construction administration, general construction, forensics, and property loss consulting. She specializes in expert witness testimony related to architectural and general construction issues, personal injury defect and accident investigation, building enclosure investigation and repair including waterproofing, roofing and fenestration, forensic architecture, litigation support, property loss evaluation, code upgrade review, peer review and quality assurance services. Ms. Myers has worked in the forensic field for over 20 years and has provided consulting expertise on a variety of project types including single and multi-family residential, industrial, health care, hospitality, office, commercial, educational, and retail....

Jose Roman Ramos, PE, CGC m2e Consulting Engineers

Miami, Florida
Construction, Engineering - Opinion of Probable Cost (All Construction Disciplines), Electrical Engineering, Forensic Engineering, Construction Defects, Construction Claims & Construction Management
...As a multi-disciplinary engineer, Roman’s areas of expertise include concrete, electrical, steel, and masonry design, construction defect inspections, and building code forensic services for commercial and residential structures from the ground and air.

Michael R. Spreckelmeier

Fort Myers, Florida
Construction, Building Inspection - Residential construction consultant, Construction consultant, Construction consultant for homeowners, Homeowner consultant, Construction consulting services, General contractor consulting, Building construction consultants, Attorney Consultation, Residential attorney consultation
...He is a state-certified building inspector and general contractor who also owned and operated a reputable design-build remodeling firm in SWFL for 30 years. As such, he offers expertise in a variety of disciplines, drawing upon his many years of personal, hands-on construction experiences and a thorough working knowledge of his craft. Driven by excellence and honor, Spreck Construction Consulting enjoys helping legal professionals by preventing, identifying, and mitigating construction risk. He supports attorneys in numerous ways, including: • Building code, permits, and other municipal legal reviews • Industry standard benchmarking and comparisons • Damage assessments and accountability determinations • Quality control oversights and other detailed examinations

James V Hanna, II, AIA, NCARB Hanna Design Alliance

DECATUR, Georgia
Construction Defects, Architecture - Envelope , Construction, Commercial, Residential, Stucco, Water Intrusion, Roofing, Accessibility, Windows, Sound, Fire, Balcony, Waterproofing, Brick, Siding, Codes, ADA, Air Barrier, Wood, Zoning
...Jim is the founder of Hanna Design Alliance, LLC. hannada.com and his career has spanned building types including multifamily apartment, condominium, resort, hotel, office, medical, and recreational design. With a focus on the technical aspects of architecture and the built environment, he has been responsible for waterproofing detailing, contractual agreements, and design management including specialty consultants. Mr. Hanna is a member of the American Institute of Architecture, NCARB, International Code Council, and the National Fire Protection Association.

William Henry, PhD, NCARB RGA Design Forensics LLC

Georgia
Premises Liability, Disaster Recovery - Accident Investigation, Building Codes, ADA, Accessibility, Slip Trip & Fall, Forensic, Architecture, Engineering, E&O, Errors and Omissions, Construction Defects, Mold, Cruise Ship, Maintenance, Building Inspection, Insurance Claims, Disaster Recovery, Failure Analysis, Property Insurance
...Henry, our lead expert, utilizes three components in his case development: (1) a detailed timeline, (2) an analysis of the governing codes and documentation, and (3) the application of the facts to those governing codes. His reports and testimony are presented in a simple, clear manner that is easily understood. This approach has had a proven impact on the outcomes of past matters, whether in settlement, mediation, arbitration, or at trial. RGA Design Forensics’ main areas of expertise are premises liability, property insurance litigation, and architectural errors and omissions (E&O) claims. Premises Liability - Whether a slip trip & fall or some other incident, RGA works with both plaintiff and defense counsels to determine adherence to or deviation from governing codes, standards, and guidelines around the site. This information is vital in determining causality in a case....

Gary Stringham

Boise, Idaho
Software Engineering, Intellectual Property - Copyright, Copyright Infringement, Embedded Systems, Firmware, Patent Infringement, Patents, Printers, Software, Software Patents, Software Review, Source Code, Trade Secrets
Thought leader in the design and testing of software, firmware, and hardware. (Firmware is software that runs machines and devices.) Over 30 total years of professional engineering experience. This includes 15 years with Hewlett-Packard’s LaserJet printer design lab which, among other things, resulted in 12 US patents and 15 defensive articles. Author of the key textbook in hardware/firmware interface design, newsletters, and other articles. IEEE (Senior member), Phi Kappa Phi. Expert witness experience includes cases that have involved patents, copyrights violations, trade secrets, and other intellectual property as well as defective products. Work as an expert witness typically involves the examination of software source code and hardware designs, and reverse-engineering the designs of others. Has written expert reports and testified at deposition....

Joseph J Jaskulski, PE Project Performance Group LLC

Evanston, Illinois
Mechanical Engineering, Energy - Power, generation, power plant, operation, maintenance, commissioning, testing, performance, insurance, construction, defect, efficiency, turbine, boiler, contractor, design build, EPC, infrastructure, gas, coal, steam, failure, wind, solar, boiler, turbine, wood, waste, root cause, cost, estimate
...Large scale multi-billion-dollar project experience Expert witness on multiple technical and commercial issues in arbitration, state and federal court, and regulatory commission environments, including: Coal-fueled power plant performance shortfall and delay in completion Steam turbine replacement due to performance shortfall Air-cooled condenser performance shortfall Multi-hundred-million-dollar gas turbine combined cycle power plant completion delay Concentrated solar facility bankruptcy due to construction delay and defects Retail electricity billing dispute State-level authorization to construct multi-billion-dollar transmission line Criminal case regarding violation of the Clean Air Act Oversee municipal investigation of facility explosion investigation and corrective actions, recommendations on allowing resumption of operations Design/construction defects, breach of contract, and fraud in the construction of a multi-hundred-million-dollar wastewater treatment plant Construction...

Dale R Wheeler Systech Fire Protection LLC

PALOS PARK, Illinois
Fire, Safety - Fire Protection Engineering, Arson, Smoke Detectors, Fire Alarm, Fire System Failure, Fire Detectors, Carbon Monoxide, Fire Cause and Origin, Fire Resistance, Building and Fire Code, Explosion, Fire Safety, Means of Egress, Life Safety, Fire Sprinklers, Forensic Fire Analysis, Fire Sprinkler Leakage
...Wheeler has practiced in Fire Protection Engineering, Fire Investigation, Fire Safety, and Building and Fire Codes for 46 years. His roles have included Insurance Risk Analyst, Building Commissioner, Building Inspector, Fire Protection and Building Code Consultant, Fire Protection System Designer, System Failure Analyst, and Forensic Fire Investigator. Mr. Wheeler's Expert Witness work includes analysis of events, written reports if requested, litigation support, mediation and arbitration support, depositions, and trail testimony. Mr. Wheeler's career experience includes approximately 220 cases, 65 depositions, and 32 trial testimony's. Mr. Wheeler works nationally and worldwide.

Randy A Winters MatrixHCI, LLC

Illinois
Software Engineering, Computers - Cybersecurity, Software Architecture, Artificial Intelligence, Cryptocurrency / Blockchain, Speech & Face Recognition, ESI Protocol, Social Media Forensics, Biometric Identifiers, Code Review, Patent Infringement ,Trade Secret, IPR, PTAB, Claim Analysis, Forensic Data Extraction, BIPA
...- In addition to his blockchain development experience, he designed the first cryptocurrency arbitrage system....

Fred B. Lott, AIA, ARA, CSI Fred Lott Architect

Indiana
Architecture, Construction Defects - Architect & Engineer Negligence, Construction Defects, Fraudulent Change Orders, Construction License Agreement, Antitrust Complaint, Standard of Care Responsibility & Compliance, Warehouse Thermal Comfort, Bid Steering, Treachery & Self-Dealing Related to Professional Practice Industry Standards
...Expert Witness & Dispute Resolution 34 years Registered Architect 44 years Construction Executive 28 years Owner Representative 24 years Fred leverages his in-depth experience of leading cross-discipline teams of design & engineering professionals and construction management teams when presenting detailed opinions and support information in an understandable way. Fred’s work has included community boards, governing agencies, investors, General Services Administration - Offices of the Inspector General, FBI, multiple state courts (including Indiana, Illinois, California, Georgia, Florida, and New York), the New York County District Attorney’s Office (Labor Racketeering Unit, Construction Industry Strike Force), the New York City Office of Administrative Trials & Hearings, and the City of New York Police Department (District Attorney’s Office Squad)....

William J. Kirkham, P.E., S.E., Ph.D. APT Engineering LLC

Eudora, Kansas
Structural Engineering, Construction Defects - Codes, Concrete Failures, Steel Failures, Masonry Failures, Wood Failures, Corrosion, Seismic Design, Wind Design, Partial/Full Collapse, Prestressed Concrete, Post-tensioned Concrete, Facade performance, Cladding Failures, Vibration, Timber Construction, Timber Decay, Wood Decay, Tall Buildings
...I have designed concrete, steel, masonry and wood structures, generally commercial, government or schools. About half of my work has been design of building facades or cladding systems. Seeking new challenges, I joined the faculty at the University of Kansas in 2016, where I am allowed to continue consulting. As a Professor of Practice and Director of the Master of Civil Engineering (MCE) Program at The University of Kansas, I teach primarily graduate structural engineering courses....

Tony DiNicola, AIA, RID, APA TONY DiNICOLA ARCHITECT

Louisiana
Architecture, Slip Trip & Fall - Forensic Architecture, Architectural Design, Construction Defects, Design Defects, Accessibility Design, ADA, Fair Housing, Texas Accessibility Standards (TAS), Plan Reviews, Inspections, Fair Housing Design Standards, Cause and Origin, Water Intrusion, Roofing Failures, Building Codes, Zoning,
...DiNicola offers forensic consulting in the Following areas EXPERT WITNESS: Reports and Presentations, Certificates of Merit, Depositions and Testimony ANALYSIS OF ARCHITECTURAL SERVICES: Architect’s Standard of Care, Architect’s Errors and Omissions, Pre-Construction Services Facility Programing, Design, Bidding Services, Construction Services, Construction Administration and Post-Construction Services AMERICANS WITH DISABILITIES ACT: ADA Violations, Texas Accessibility Standards (Plan Reviews and Site Inspections), Site and Building Accessibility Compliance FAIR HOUSING: Compliance with Fair Housing design requirements CODES AND ORDINANCES: Compliance with Building Codes, Local Ordinances, Industry Standards, ADA and Fair Housing BUILDING FAILURES: Analysis of Construction and Design Defects, Cause and Origin and Failure Analysis Roofing Failures: Roofing design and detailing, evaluation of drainage conditions, code analysis, determination of cause and extent of water intrusion...

William Henry, PhD, NCARB RGA Design Forensics LLC

Louisiana
Premises Liability, Disaster Recovery - Accident Investigation, Building Codes, ADA, Accessibility, Slip Trip & Fall, Forensic, Architecture, Engineering, E&O, Errors and Omissions, Construction Defects, Mold, Cruise Ship, Maintenance, Building Inspection, Insurance Claims, Disaster Recovery, Failure Analysis, Property Insurance
...Henry, our lead expert, utilizes three components in his case development: (1) a detailed timeline, (2) an analysis of the governing codes and documentation, and (3) the application of the facts to those governing codes. His reports and testimony are presented in a simple, clear manner that is easily understood. This approach has had a proven impact on the outcomes of past matters, whether in settlement, mediation, arbitration, or at trial. RGA Design Forensics’ main areas of expertise are premises liability, property insurance litigation, and architectural errors and omissions (E&O) claims. Premises Liability - Whether a slip trip & fall or some other incident, RGA works with both plaintiff and defense counsels to determine adherence to or deviation from governing codes, standards, and guidelines around the site. This information is vital in determining causality in a case....

Ervin L Ritter, PE Ervin Ritter PE, LLC

Lafayette, Louisiana
Engineering, Environmental - Building Mechanical Systems, HVAC Systems Design, HVAC Systems Installation, HVAC Systems Controls, Plumbing Systems Design and Installation, Building Fire Protection systems, Indoor Air Quality, Indoor Environmental Quality, Mechanical Codes , Plumbing Codes, National Fire Protection Codes
...Member of the following professional organizations: ASHRAE AIHA LES NSPE NFPA AIA AEE IBC code IMC code IPC code

Robert L Fulmer Fulmer Associates LLC

Durham, Maine
Construction Defects, Construction - Slate Roofing, Copper Roofing, Steeple Inspection, Tower Inspection, Roof Design, Historic Restoration, Building Envelope, Waterproofing, Cedar Roofing, Tile Roofing, Single-Ply Membrane, Roofing Specification, metal roofing, masonry, walls, windows, below-grade, waterproofing, construction defects
As Principal of Fulmer Associates LLC, Robert Fulmer utilizes his 38 years of professional practice and consulting experience within the building enclosure construction industry, to provide building exterior design, assessment and project management services for institutional, academic and residential structures through the application of contemporary building science and current industry standards. Robert’s professional experience includes all building enclosure systems, including all types of low-slope and steep-slope roof systems, with extensive expertise in slate, copper, tile and wood roof systems. Also, included are all types of masonry wall and window systems, stucco, plaza decks and below-grade waterproofing. He is a published author and has lectured throughout the U.S. on various exterior building science topics....

Brian K Bramel, SE, PE, Ph.D. Bramel Engineering

Tracys Landing, Maryland
Structural Engineering, Construction Defects - Construction, construction site safety, concrete, open web joist, light gage steel, underpinning, mechanical engineering, product defects, failure analysis, finite elements, design build
...Bramel has over 30 years of broad Engineering experience in all aspects of the construction process: from design through construction and service. Dr. Bramel has effectively served as an Expert Witness and a litigation advisor on hundreds of cases in the past 10 years. He has advised in Construction Defect, Building and Material Failures, Product Liability, Personal Injury, Construction Work Site Injuries, Multi-Employer Worksite Matters, as well as building code compliance and insurance claims throughout the mid-Atlantic region. His expertise in Civil, Mechanical, and Structural Engineering allows a broad perspective of potential matters beyond the traditional Engineering solutions. Dr. Bramel is a practicing Licensed Professional Engineer in Virginia, Maryland, West Virginia, Pennsylvania, Ohio, New York, and Delaware, a practicing Licensed Structural Engineer in Washington, D.C., and a Model PE NCEES record holder....

Jason S. Kiddy, PhD, PE, CFEI Aither Forensic Engineering

Gambrills, Maryland
Mechanical Engineering, Products Liability - Plumbing, Construction Defects, Premises Liability, Industrial Accidents, Heavy Equipment, Hunting Equipment, Manufacturing, Aviation, Origin and Cause, Pressure Vessels, Intellectual Property, Fire and Explosion Investigation
...Kiddy's work experience includes the oil and gas industry, aircraft and helicopter design, marine structures, wind turbines, and telecommunications. From a technical perspective, Dr. Kiddy has expertise in mechanical design, engineering materials, plumbing/HVAC systems, corrosion, fire origin and cause, codes and standards, and warnings/instructions. From a product design standpoint, Dr. Kiddy's experience includes all aspects of a product life cycle such as early stage R&D, product development and qualification, manufacturing, quality control, and failure analysis. Dr. Kiddy is a registered professional engineer in five states, a certified fire and explosion investigator, and an FAA certified drone pilot. Dr. Kiddy's also has substantial experience in intellectual property matters ranging from invention disclosures, patent writing, patent prosecution, and continuing through IP disputes. Dr....

Tara L Pase Bramel Engineering, LLC

Tracys Landing, Maryland
Structural Engineering, Civil Engineering - Construction Defect, Concrete, Seismic, Retaining Walls, OSHA, Building Codes, Steel, Earthquake, Stormwater Management, Civil Engineering, Failure Analysis, Wood, Wind, Construction, Structural Engineering, Strength of Materials, Masonry, Foundations, Construction Accident, Design and Analysis
Civil/Structural Engineering Construction Defects Building Codes OSHA Failure Analysis Strength of Materials Concrete/Steel/Wood/Masonry Design Concrete/Steel/Wood/Masonry Analysis Seismic Design and Analysis Wind Design and Analysis Foundations and Retaining Structures Grading and Soil Properties Field Repair Designs Stormwater Management Component/Connection Design and Analysis Construction Cost Estimates Building Envelope (Moisture Barriers) Construction Management Registered Professional Engineer, State of New York, License No.087752 Registered Professional Engineer, State of Maryland, License No.42640 Registered Professional Engineer, Commonwealth of Virginia, License No.051210 Registered Professional Engineer, State of New Jersey, License No.24GE05239300

Robert L Fulmer Fulmer Associates LLC

Massachusetts
Construction Defects, Construction - Slate Roofing, Copper Roofing, Steeple Inspection, Tower Inspection, Roof Design, Historic Restoration, Building Envelope, Waterproofing, Cedar Roofing, Tile Roofing, Single-Ply Membrane, Roofing Specification, metal roofing, masonry, walls, windows, below-grade, waterproofing, construction defects
As Principal of Fulmer Associates LLC, Robert Fulmer utilizes his 38 years of professional practice and consulting experience within the building enclosure construction industry, to provide building exterior design, assessment and project management services for institutional, academic and residential structures through the application of contemporary building science and current industry standards. Robert’s professional experience includes all building enclosure systems, including all types of low-slope and steep-slope roof systems, with extensive expertise in slate, copper, tile and wood roof systems. Also, included are all types of masonry wall and window systems, stucco, plaza decks and below-grade waterproofing. He is a published author and has lectured throughout the U.S. on various exterior building science topics....

Martin A. Smargiassi, AIA Innovative Collaborations, Inc.

Boston, Massachusetts
Architecture, Construction - Value Analysis/Engineering, Construction Defects, Building Codes, Reconstruction, Cost Estimation, Investigation and Testing, Document Management, Contract Document Analysis, Accessibility Design
...Experienced expert witness in arbitration and mediation and a litigation resource in design, contracts, construction management and consulting. Projects: Residential and commercial

Randy A Winters MatrixHCI, LLC

Massachusetts
Software Engineering, Computers - Cybersecurity, Software Architecture, Artificial Intelligence, Cryptocurrency / Blockchain, Speech & Face Recognition, ESI Protocol, Social Media Forensics, Biometric Identifiers, Code Review, Patent Infringement ,Trade Secret, IPR, PTAB, Claim Analysis, Forensic Data Extraction, BIPA
...- In addition to his blockchain development experience, he designed the first cryptocurrency arbitrage system....

Jeffrey E Bartrem, C.B.I. Professional Inspection Consultants, Inc.

Williamston, Michigan
Building Inspection, Construction - Premises Liability, Property Litigation,Negligence Actions, Building Code, Wrongful Death,Residential & Commercial Structures,Fire,Electrical,Mechanical, Plumbing,Zoning,Slip & Fall,Workmanship,Water Testing,Building Inspection, Maintenance, Safety,Code Research, Cost Estimating
...Certified Building Inspector, I.C.B.O - International Code Council Registered Building Inspector, State of MI Registered Building Official, State of Michigan Registered Plan Reviewer, State of MI 2009 International Accreditation Service, International Code Council, Lead Evaluator Training 1998 Professional Development Committee, International Conference of Building Officials 1987 Rehabilitation Construction Specialist, National Association of Housing and Redevelopment Officials 1983 Licensed Residential Builder, State of MI 2010 International Accreditation Service, International Code Council, Building Department Evaluator, Construction Practices Assessment Team, Abu Dhabi, United Arab Emirates 2009 Faculty, Michigan State Univ., School of Planning, Design and Construction, Construction Management Program, Adjunct Instructor, Commercial, Fire and Residential Building Codes 1984 President, Professional Inspection Consultants, Inc....

Jeffrey A Grusenmeyer, RA, NCARB, MPE, CBO Jeffrey A. Grusenmeyer & Associates, Inc.

Michigan
Architecture, Construction Defects - Forensic Architect, Building Inspection, Architectural Professional Liability, Water Intrusion & Damage, ADA Consulting, Slip Trip and Fall, Building Code, Building Envelope, Waterproofing, Roofs, Fenestration, Construction Administration, Construction Standards, Standard of Care, Design Errors
Responsible for field investigations, failure analysis, building code research, repair solutions, expert reports, trial preparation, and expert witness testimony. Completed more than 10,000 plan examinations for numerous jurisdictions. Technical investigations and research of suspected design and construction problems. Verify and compare as-built conditions, design parameters, building jurisdiction requirements and applicable industry standards of care. Provide quality assurance, evaluation and observation of in-progress construction of commercial and residential structures for conformance to design, material and workmanship standards. Provide expert services for Architecturally related personal Injury matters. NCARB National Council of Architectural Registration Boards Certified Certified as a Building Official by the Council of American Building Officials....

Robert (Rob) C Hoffman Jr, PE, CFEI Creative Product Solutions, LLC

Coloma, Michigan
Engineering, Safety - fire, shock, burn, appliance, product, design, test, code, safety, failure, analysis, warning, instruction, literature, product safety, containment, inspection, litigation, product liability, expert
Specialize in design for safety, force failure testing, and product litigation support for the consumer goods industry. Knowledge source in the US on appliance fires, with specific detailed knowledge on dryer fires and their causes. Qualifications: Registered professional engineer in the state of Michigan Certified fire and explosion investigator (CFEI) Master certified in design for safety Master certified in force failure testing Certified in experimental statistics and statistical process control Member of the UL Standards Technical Panel for appliance codes related to clothes washers and dryers I worked in the consumer goods industry in appliances for over 28 years, which gave me the opportunity to serve on the dryer safety committee for the American Home Appliance Manufacturers (AHAM), as well as work extensively with Underwriters Laboratory ( UL) and CSA....

Michael R Smith AdventureSmith, Inc.

Rochester Hills, Michigan
Athletics & Recreation, Risk Management - zipline, zip lines, zipline accident, zipline braking, zipline brake system, zipline construction, zipline death, zipline safety, residential/backyard zipline, zipline standards, aerial adventure course, aerial adventure course standards, ropes course, challenge course, climbing, ACCT, ASTM, NAARSO
...Smith is an industry leader and proven business, marketing, and risk management consultant with 25 years of experience designing and developing award-winning aerial adventure parks and 29 years of experience delivering adventure-based tours, adventure programs, and team and leadership development programming. He has worked with numerous Fortune 500 companies as a business consultant, authored and published climbing guides, worked as a Field Instructor for the Outward Bound School, and is regularly retained as a zip line and adventure park expert witness. Smith maintains a niche consultancy, AdventureSmith, Inc., focused on risk management, marketing, business consulting, and staff development systems for the aerial adventure course market. AdventureSmith, Inc. has provided support to many challenge courses, zip lines, and aerial adventure parks in the U.S.A. and Canada....

Bradley E Layton, PhD PE Human Powered Future PLLC

Missoula, Montana
Accident Reconstruction, Biomedical Engineering - accidents, biomechanics, diabetes, dynamics, energy, engineering, failure, forensics, imaging, injury, materials, mechanics, nanotechnology, neurology, neuropathy, patents, personal injury, physics, proteins, slip trip & fall, soft tissue, solar, spine, statics, statistics, vehicle
American Concrete Institute Member ASME member IEEE-EMBS Editor Author - Molecular and Cellular Biomechanics Associate Teaching Professor - Drexel University Associate Professor - University of Montana Elite Athlete - United States Rowing Team 1995 & 1997 Fire Protection Engineer - US Department of Energy - Savannah River Site Founding Member - Insurance Engineering Blockchain Consortium International Code Council Member Inventor - AFM Nanomanipulation & Surgical Patents Lunar Scientist - US Department of Energy - Office of Space Machinist - Merlin Metalworks - titanium bicycle design & Stillwater - Kevlar boat design Oath of the Engineer - Engineer's equivalent of Hippocratic Oath National Society of Professional Engineers Post-doctoral Fellow - University of Michigan MRI laboratory Recipient - Montana Governor's Innovator Award Scientist - 100+ papers and abstracts

Captain Gregory M Tylawsky, MBA, CMMar, AFNI Maritime Expert Group, Inc.

Carson City, Nevada
Maritime, Accident Reconstruction - Piloting, Ship handling, Ship routing, Weather, anchoring, heavy weather, anchor, allision, collision, ship, Captain, tug, STCW, USCG, IMO, Standard of care, COLREGS, VTS, Harbor, Pilot ladder, cruise ship, freighter, Master, Officer, Merchant Marine, Jones Act, Navigation
...Code to serve in the capacity or capacities specified, subject to any limitations indicated. The Government of the United States of America certifies: GREGORY MICHAEL TYLAWSKY has been duly qualified in accordance with the provisions of regulation(s) III/1; II/2; II/3; II/4; II/5; IV/2; VI/1; VI/2; VI/3; VI/4; VI/5; VI/6 Of the above Convention, as amended, and has been found competent to perform the following functions, at the levels specified, subject to any limitation indicated until 06-NOV-2024. Master Officer in charge of a navigational watch (OICNW). Able Seafarer – Deck. Rating forming part of a navigational watch (RFPNW). Proficiency in survival craft and rescue boats other than fast rescue boats (PSC). Medical First-Aid Provider. Person in Charge of Medical Care. Advanced Firefighting. Basic Training. GMDSS Operator. Vessel Security Officer. Vessel Personnel with Designated Security Duties. Security Awareness.

Robert L Fulmer Fulmer Associates LLC

New Hampshire
Construction Defects, Construction - Slate Roofing, Copper Roofing, Steeple Inspection, Tower Inspection, Roof Design, Historic Restoration, Building Envelope, Waterproofing, Cedar Roofing, Tile Roofing, Single-Ply Membrane, Roofing Specification, metal roofing, masonry, walls, windows, below-grade, waterproofing, construction defects
As Principal of Fulmer Associates LLC, Robert Fulmer utilizes his 38 years of professional practice and consulting experience within the building enclosure construction industry, to provide building exterior design, assessment and project management services for institutional, academic and residential structures through the application of contemporary building science and current industry standards. Robert’s professional experience includes all building enclosure systems, including all types of low-slope and steep-slope roof systems, with extensive expertise in slate, copper, tile and wood roof systems. Also, included are all types of masonry wall and window systems, stucco, plaza decks and below-grade waterproofing. He is a published author and has lectured throughout the U.S. on various exterior building science topics....

C Martin Nowland, PE, CEM Nowland Services, PLLC

Wolfeboro, New Hampshire
Electrical Engineering, Energy - Electrical engineering & design, industrial automation & control systems, instrumentation integration, process control, programmable logic controllers hardware & software, electrically hazardous areas, code evaluations, safety, electric power generation & distribution systems, power plants design
Electrical engineering, automation and control systems design, instrumentation integration, process control, intrinsically safe (IS) circuits, surge protection, installation, programming & commissioning. Energy efficient systems, energy audits, prototype technologies design. Electrical design specifications & drawings, equipment and systems specifications including large machinery, for skids, containers, buildings, or entire campuses. Electrically hazardous areas. Code and/or safety evaluations. Electrical power generation & distribution, power plants, motors, motor control centers (MCC), variable frequency drives (VFD), transformers, switchgear, uninterruptible powers supplies (UPS). Commissioning and startup. Flammable gas facilities including natural gas, liquefied natural gas (LNG), compressed natural gas (CNG), liquefied petroleum gas (LPG), liquid nitrogen, propane and hydrogen.

Charles W. Bowden, CLU, ChFC FSP

Smithville, New Jersey
Insurance, Financial - Life Insurance, Health Insurance, Disability Insurance, Financial Planning, Life Insurance Funding, Policy Valuation
...In addition to his thirty plus years of experience, he has achieved both industry recognized designations of Chartered Life Underwriter (CLU) and Chartered Financial Consultant (ChFC). As a Qualified Continuing Education Instructor, he teaches other licensed insurance professionals about the changing structure of the income and estate tax code, and planning strategies. Additionally, Charlie uses his experience to provide expert testimony in State and Federal Court. Charlie is a member of the Society for Financial Service Professionals, as well as a past member of their Board Authority of Directors. He maintains registration with the Financial Industry Regulatory Authority (FINRA). He is an investment Advisor Representative (IAR). As of August 2022 Retired as a Register Representative but am maintaining all insurance licensing. Securities Offered Through TFS Securities, Inc....

Baw Chng BAWMAN LLC

Cherry Hill, New Jersey
Internet, Computers - Intellectual Property, Patents, Networking, Telecommunications, Wi-Fi, Cellular Communications, Wireless, Internet, Mobility, Broadband, Internet of Things, IoT, Cloud Computing, 3GPP, LoRa, Wi-Max, WPAN, TCP/IP, Protocols, Standards, Web Services, API, Big Data, Plastic Optical Fiber, SDN, NFV, SON
...Diverse software coding experience. MSCS, BSEE, & BSCoE Washington University in St. Louis. Published author. Technical Skills and Knowledge Include: 3GPP and 3GPP2 families of cellular mobile broadband radio access and core network standards, small cells, femtocell, inter-technology handover and roaming IEEE 802.11 (Wi-Fi, mesh, infrastructure), 802.3 (Ethernet), 802.15 (WiMAX), 802.16 (WPAN) families of standards Internet standards and protocols, TCP/IP, UDP, RTP, DHCP, DNS, ARP, GRE, etc....

D.R. Foster, PhD, PE Expert Welding Engineering and Inspection

Swedesboro, New Jersey
Failure Analysis, Safety - Welding Engineering, Weld Failures, Welding Design, Industrial Safety, 3D Printing of Metals, Welding, Welding Safety, Inspection, Welding Metallurgy, Welding Defects, Torch cutting, Forensics, Codes Compliance, Non-Destructive Testing, Manufacturing, Marine, Navy, Aerospace, Military, ASME, AWS
...Foster is an expert in regard to the design, manufacture, testing, and safety associated with welded structures. In addition to Dr. Foster’s significant experience in the field of welding engineering in both academia and industry, Dr. Foster possesses a BS, MS, and PhD in Welding Engineering. Strongly dedicated to his craft, Dr. Foster has earned multiple certifications related to fields of welding engineering and inspection. These certifications include Certified Welder (CW), Certified Welding Inspector (CWI), Certified Welding Supervisor (CWS), Certified NDT Level III Inspector (NDT III) and Licensed Professional Engineer (PE), all of which have prepared Dr. Foster exceptionally well to properly analyze failures and other welding problems that are the subject of litigation. Dr....

Michael A. Pollock, P.E. Cogent Experts, LLC

New Jersey
Engineering, Construction Defects - Standard of care, construction defect, construction delay, engineering, mechanical engineering, HVAC, project management, construction schedule analysis, manufacturing, product liability, power, refrigeration, fire, explosion, automotive, forensics, failure analysis, engineering standard of care
...Developed an expert opinion and report for general construction issues, constructability, design revisions, and corresponding delay analysis for mechanical, HVAC, electrical, smoke and fire, structural, security and building automation systems. Reviewed findings with multi – discipline experts for mediation, leading to a negotiated settlement favorable to our client. Municipal Building/Facility - Northern NJ - Evaluated and provided expert witness mediation testimony regarding a $3M construction delay claim by general contractor against municipal facility concerning an $8M renovation and new construction project. Analysis included review of plaintiff’s claim, project schedules, critical path & time impact considerations, delays, pay applications, contract terms, change orders, consequential & liquidated damages, lien and bond issues, correspondence and numerous other project documents. Guided mediation to quickly develop a very favorable settlement for our client....

Jeffrey D. Zwirn, CPP, CFPS, CFE, SET, FASI&T, CHPA-IV, MBAT IDS Research & Development, Incorporated

Tenafly, New Jersey
Security, Fire - Burglar Alarm, Alarm System, Security System, Alarm & Security, Central Station, Telephone Line Security, Fire Alarm, Smoke Detection, Carbon Monoxide, Panic & Holdup, Physical Security, Access Control, Video Surveillance Systems, Manufacturer Specifications, UL & NFPA Standards, Industry Standards.
...Standard Technical Panels (STP) and is a former Principal Technical Committee Panel Member, Appointed by NFPA 72®, in the Special Expert Category, for The National Fire Alarm Code And The National Fire Alarm and Signaling Code. As an active designated Expert Instructor to the New York City Police Deparment, the (Nation’s Leader In Law Enforcement) for over 22 years, Jeffrey has developed training curriculum and test examinations for the New York City Police Department (NYPD). Mr. Zwirn has also provided expert witness, consultation, and /or training services to the technical community of the alarm, central station, security and law enforcement communities....

Brian K Bramel, SE, PE, Ph.D. Bramel Engineering

New York
Structural Engineering, Construction Defects - Construction, construction site safety, concrete, open web joist, light gage steel, underpinning, mechanical engineering, product defects, failure analysis, finite elements, design build
...Bramel has over 30 years of broad Engineering experience in all aspects of the construction process: from design through construction and service. Dr. Bramel has effectively served as an Expert Witness and a litigation advisor on hundreds of cases in the past 10 years. He has advised in Construction Defect, Building and Material Failures, Product Liability, Personal Injury, Construction Work Site Injuries, Multi-Employer Worksite Matters, as well as building code compliance and insurance claims throughout the mid-Atlantic region. His expertise in Civil, Mechanical, and Structural Engineering allows a broad perspective of potential matters beyond the traditional Engineering solutions. Dr. Bramel is a practicing Licensed Professional Engineer in Virginia, Maryland, West Virginia, Pennsylvania, Ohio, New York, and Delaware, a practicing Licensed Structural Engineer in Washington, D.C., and a Model PE NCEES record holder....

Barry Formisano Formisano & Associates, Inc.

Gardiner, New York
Failure Analysis, Metallurgy - Weld Failures, Welding Safety, Welding Processes, Weld Inspection and testing, Weld Engineering, Weld Metallurgy, Brazing and soldering, Manufacturing Weld Defects, Weld Structural Fabrication, Pipeline Weld Failures, Welding Codes Compliance, Construction Weld Failures, Welding Consulting
...As a consulting and testifying expert witness I have been qualified by Courts in several states; and have been retained by both plaintiffs and defendants for lawsuits involving product liability, manufacturing defects, personal injury and code compliance. I hold degrees in Welding Technology, Mathematics and Science; in addition to college level teaching credentials in the field of welding. Previous employment includes positions with the United States Department of Energy (DOE) and the Naval Nuclear Propulsion Laboratory; these positions required a high level security "Q" clearance. I have been an AWS Certified Welding Inspector for over 30 years. As an independent welding consultant I routinely author welding procedures and welding specifications, conduct welder qualification testing, perform weld inspections and weld failure analysis for many Fortune 500 companies....

Fred B. Lott, AIA, ARA, CSI Fred Lott Architect

New York
Architecture, Construction Defects - Architect & Engineer Negligence, Construction Defects, Fraudulent Change Orders, Construction License Agreement, Antitrust Complaint, Standard of Care Responsibility & Compliance, Warehouse Thermal Comfort, Bid Steering, Treachery & Self-Dealing Related to Professional Practice Industry Standards
...Expert Witness & Dispute Resolution 34 years Registered Architect 44 years Construction Executive 28 years Owner Representative 24 years Fred leverages his in-depth experience of leading cross-discipline teams of design & engineering professionals and construction management teams when presenting detailed opinions and support information in an understandable way. Fred’s work has included community boards, governing agencies, investors, General Services Administration - Offices of the Inspector General, FBI, multiple state courts (including Indiana, Illinois, California, Georgia, Florida, and New York), the New York County District Attorney’s Office (Labor Racketeering Unit, Construction Industry Strike Force), the New York City Office of Administrative Trials & Hearings, and the City of New York Police Department (District Attorney’s Office Squad)....

John Mclean, RA, NCARB John Mclean Architect

White Plains, New York
Architecture, Construction Defects - Architectural Practice-Standard of Care, Zoning Regulations, Building Laws-Codes, Building Design/Engineering, Architectural Standards, Building/Site Planning,ADAAG Compliance, Construction Disputes/Claims, Building Exteriors/Envelopes, Reference Standards, Fire-rated Assemblies, Building Science
JOHN MCLEAN ARCHITECT See complete professional history including projects, lectures, exhibitions and awards at: https://johnmcleanarchitect.com/architect-mclean.htm CREDENTIALS Architect: Practice registered in New York; Licenses have been issued by NY, NJ, PA, IL, CT, LA, & Israel ■ Board Certified, National Council of Architectural Registration Boards (NCARB) EXPERT TESTIMONY Forty-five years of design experience as a practicing architect and industrial designer enhances the depth and authority of Mclean’s testimony. Has prepared and presented architectural testimony regarding design, construction, professional practice, land use and zoning on behalf of architects, property and building owners, developers, civic groups, and home owners....

Steven Pietropaolo, MS, P.E., CFEI LGI Forensic Engineering, PC

North White Plains, New York
Engineering, Forensic Science - Forensic Engineering, Explosions, Electrical Engineering, Mechanical Engineering, Product Liability, Fires, Fire Protection, Appliances, Construction, Building Defects, Failure Analysis, Laboratories & Testing, Building Defects, Plumbing
...He has knowledge of codes and standards used in construction and industry including building codes and safety codes. He is an expert in investigating and opining on New York State Labor Law cases (§200, §240(1) and §241(6)) involving falls, electrical shock and other construction related accidents, including evaluation and analysis of the New York State “Industrial Code Rule 23”. He has provided safety engineering consulting and expert services to manufacturers, construction companies and retailers. His expertise is in the field of forensic investigations of; product defects, fires/explosions, fire protection systems, accidents/injuries, building failures, and electro/mechanical system failures. He provides expert services involving product design, manufacturing defects and warnings/instructions. He has extensive experience in Utility Company procedures/equipment and investigating major incidents involving electrical, gas, steam system failures, and construction accidents....

Randy A Winters MatrixHCI, LLC

New York
Software Engineering, Computers - Cybersecurity, Software Architecture, Artificial Intelligence, Cryptocurrency / Blockchain, Speech & Face Recognition, ESI Protocol, Social Media Forensics, Biometric Identifiers, Code Review, Patent Infringement ,Trade Secret, IPR, PTAB, Claim Analysis, Forensic Data Extraction, BIPA
...- In addition to his blockchain development experience, he designed the first cryptocurrency arbitrage system....

Jeffrey A Grusenmeyer, RA, NCARB, MPE, CBO Jeffrey A. Grusenmeyer & Associates, Inc.

Fairview Park, Ohio
Architecture, Construction Defects - Forensic Architect, Building Inspection, Architectural Professional Liability, Water Intrusion & Damage, ADA Consulting, Slip Trip and Fall, Building Code, Building Envelope, Waterproofing, Roofs, Fenestration, Construction Administration, Construction Standards, Standard of Care, Design Errors
Responsible for field investigations, failure analysis, building code research, repair solutions, expert reports, trial preparation, and expert witness testimony. Completed more than 10,000 plan examinations for numerous jurisdictions. Technical investigations and research of suspected design and construction problems. Verify and compare as-built conditions, design parameters, building jurisdiction requirements and applicable industry standards of care. Provide quality assurance, evaluation and observation of in-progress construction of commercial and residential structures for conformance to design, material and workmanship standards. Provide expert services for Architecturally related personal Injury matters. NCARB National Council of Architectural Registration Boards Certified Certified as a Building Official by the Council of American Building Officials....

William Henry, PhD, NCARB RGA Design Forensics LLC

Ohio
Premises Liability, Disaster Recovery - Accident Investigation, Building Codes, ADA, Accessibility, Slip Trip & Fall, Forensic, Architecture, Engineering, E&O, Errors and Omissions, Construction Defects, Mold, Cruise Ship, Maintenance, Building Inspection, Insurance Claims, Disaster Recovery, Failure Analysis, Property Insurance
...Henry, our lead expert, utilizes three components in his case development: (1) a detailed timeline, (2) an analysis of the governing codes and documentation, and (3) the application of the facts to those governing codes. His reports and testimony are presented in a simple, clear manner that is easily understood. This approach has had a proven impact on the outcomes of past matters, whether in settlement, mediation, arbitration, or at trial. RGA Design Forensics’ main areas of expertise are premises liability, property insurance litigation, and architectural errors and omissions (E&O) claims. Premises Liability - Whether a slip trip & fall or some other incident, RGA works with both plaintiff and defense counsels to determine adherence to or deviation from governing codes, standards, and guidelines around the site. This information is vital in determining causality in a case....

Keith A. Bergman, PE Bergman Engineering, LLC

Harleysville, Pennsylvania
Premises Liability, Traffic Engineering - Accident Reconstruction, Civil Engineering, Codes and Standards, Construction, Highway and Street Design, Job-Site Safety, Motor Vehicle Accidents, Premises Liability, Slip Trip and Fall, Transportation, Traffic Engineering, Walkway Surface and Pavement Evaluation
Our mission: Bringing clarity to complexity. Bergman Engineering is a forensic engineering firm that provides objective investigative analysis and consulting services as well as expert witness testimony. Hired for our expertise, we utilize our knowledge and experience to evaluate cases and claims with regard to civil engineering concepts. This can extend to a number of different practice areas for both plaintiff and defense counsel. Our case experience ranges from small private claims to large civil claims. We have consulted in complex claims and litigation on behalf of corporations, attorneys, insurance companies, and municipal/government agencies. Certified Professional Engineer: California, Delaware, Florida, Illinois, Maryland, Massachusetts, Michigan, New Hampshire, New Jersey, New York, Ohio, Pennsylvania and Virginia.

Anthony Bruttaniti, AIA, LEED AP BD+C Bruttaniti Architecture LLC

Philadelphia, Pennsylvania
Architecture, Construction Defects - Architect, ADA compliance, Zoning, Building codes, Building product liability, Slip Trip Fall, Construction defects, Building envelope, Building materials, Construction accidents, Building demolition, Fire damage, Water damage, Structure collapse, Building personal injury
Anthony Bruttaniti, AIA LEED AP BD+C, is a registered Architect in business for 30+ years in Philadelphia with experience in both Residential and Commercial Building Design. For the last three decades, Mr. Bruttaniti has offered space planning and design, site planning and zoning, architectural detailing, construction drawings and construction administration. His responsibilities and duties have included project acquisition and marketing; Project Development from concept ideas thru to construction; Client interaction, communication, and proposal writing; Zoning and Construction drawings for building permits; Managing structural and MEP engineers for the project; and problem-solving during construction. Mr. Bruttaniti was honored with an award for Excellence in Planning & Design from the Montgomery County Planning Commission, PA for an adaptive building re-use and sustainable design for a new Public Library in North Wales, PA. Litigation Support - Mr....

Jeffrey A Grusenmeyer, RA, NCARB, MPE, CBO Jeffrey A. Grusenmeyer & Associates, Inc.

Pennsylvania
Architecture, Construction Defects - Forensic Architect, Building Inspection, Architectural Professional Liability, Water Intrusion & Damage, ADA Consulting, Slip Trip and Fall, Building Code, Building Envelope, Waterproofing, Roofs, Fenestration, Construction Administration, Construction Standards, Standard of Care, Design Errors
Responsible for field investigations, failure analysis, building code research, repair solutions, expert reports, trial preparation, and expert witness testimony. Completed more than 10,000 plan examinations for numerous jurisdictions. Technical investigations and research of suspected design and construction problems. Verify and compare as-built conditions, design parameters, building jurisdiction requirements and applicable industry standards of care. Provide quality assurance, evaluation and observation of in-progress construction of commercial and residential structures for conformance to design, material and workmanship standards. Provide expert services for Architecturally related personal Injury matters. NCARB National Council of Architectural Registration Boards Certified Certified as a Building Official by the Council of American Building Officials....

Jason S. Kiddy, PhD, PE, CFEI Aither Forensic Engineering

Pennsylvania
Mechanical Engineering, Products Liability - Plumbing, Construction Defects, Premises Liability, Industrial Accidents, Heavy Equipment, Hunting Equipment, Manufacturing, Aviation, Origin and Cause, Pressure Vessels, Intellectual Property, Fire and Explosion Investigation
...Kiddy's work experience includes the oil and gas industry, aircraft and helicopter design, marine structures, wind turbines, and telecommunications. From a technical perspective, Dr. Kiddy has expertise in mechanical design, engineering materials, plumbing/HVAC systems, corrosion, fire origin and cause, codes and standards, and warnings/instructions. From a product design standpoint, Dr. Kiddy's experience includes all aspects of a product life cycle such as early stage R&D, product development and qualification, manufacturing, quality control, and failure analysis. Dr. Kiddy is a registered professional engineer in five states, a certified fire and explosion investigator, and an FAA certified drone pilot. Dr. Kiddy's also has substantial experience in intellectual property matters ranging from invention disclosures, patent writing, patent prosecution, and continuing through IP disputes. Dr....

Michael A. Pollock, P.E. Cogent Experts, LLC

Bryn Mawr, Pennsylvania
Engineering, Construction Defects - Standard of care, construction defect, construction delay, engineering, mechanical engineering, HVAC, project management, construction schedule analysis, manufacturing, product liability, power, refrigeration, fire, explosion, automotive, forensics, failure analysis, engineering standard of care
...Developed an expert opinion and report for general construction issues, constructability, design revisions, and corresponding delay analysis for mechanical, HVAC, electrical, smoke and fire, structural, security and building automation systems. Reviewed findings with multi – discipline experts for mediation, leading to a negotiated settlement favorable to our client. Municipal Building/Facility - Northern NJ - Evaluated and provided expert witness mediation testimony regarding a $3M construction delay claim by general contractor against municipal facility concerning an $8M renovation and new construction project. Analysis included review of plaintiff’s claim, project schedules, critical path & time impact considerations, delays, pay applications, contract terms, change orders, consequential & liquidated damages, lien and bond issues, correspondence and numerous other project documents. Guided mediation to quickly develop a very favorable settlement for our client....

James Rappoport, AIA-NCARB Daroff Design

Philadelphia, Pennsylvania
Architecture, Slip Trip & Fall - Architecture,Site Planning,Zoning, Codes,Development,Standard of Care,Liability,ADA Accessibility,Construction,Copyright,Facility Programming, Feasibility,Furniture,Finishes & Equipment,Hotels,Restaurants, Resort, Interior Design & Planning,Slip-Trip-Falls,Owner-Architect & Consultant Disputes.
James Rappoport is Principal at Daroff Design, a full service Planning, Architectural & Interior Design practice founded in 1973. The firm specializes in ground-up, renovation, and historic adaptive reuse projects for office facilities, hotels, resorts, retail and shopping facilities, restaurants, meeting, conference and training facilities, aviation terminals and entertainment projects throughout the USA and Internationally. Mr. Rappoport has provided technical consultation analysis, expert witness reports, opinions, affidavits, certificates of merit, depositions, mediation and alternative dispute resolution presentations, testimony and pre-trial support in more than 250 legal cases, for both defendants’ and plaintiffs’ legal teams. Each of the matters Mr. Rappoport has collaborated on have settled before trial. Mr. Rappoport is the author of several professional text books and trade journal articles....

Ellen Szubski, M.S., Ph.D., CXLT, CPSI, AHFP The Warren Group, Inc.

Irmo, South Carolina
Human Factors, Premises Liability - Accident Prevention, Risk Management, Illumination, Conspicuity, Visual Perception, Slip resistance, Playground Safety, Premises Liability, Lighting, Line of Sight, Driver Distraction, Roadway Markings, Environmental Conditions, Slip-Trip- Fall Evaluations, Workplace Injuries, Human Factors, OSHA
...As a CPSI, she is well versed in playground safety standards, safety design, and maintenance contributing to playground injuries and fatalities. She utilizes her knowledge of OSHA regulations, codes, and standards in her analysis of premises liability incidents and safety consulting. Ellen is a current member of the Human Factors and Ergonomics Society (HFES) and its Forensic Professional Technical Group.

Roger W. Griffith, P.E. Griffith Engineering & Consulting, Inc.

Jefferson City, Tennessee
Plumbing, HVAC - Plumbing, plumbing systems, plumbing codes, plumbing design, plumbing engineering, piping, hot water systems, scalding, Legionella, fuel gas systems, gas appliances, gas venting, carbon monoxide poisoning, HVAC, HVAC design, fire protection, sprinkler systems, construction defects, failure analysis
...His experience includes plumbing, HVAC, and sprinkler system design, forensic analysis, and expert witness consulting. For the past 15 years, Mr. Griffith has provided expert witness services, including deposition and trial testimony. In addition to plumbing, HVAC and sprinkler systems, his areas of specialty include hot water system design, hot water scalding, legionella, and venting of gas appliances as it relates to carbon monoxide poisoning. Mr. Griffith is a Board Certified Diplomate Forensic Engineer (DFE) of the National Academy of Forensic Engineers (NAFE). Prior to founding Griffith Engineering in 1997, Mr. Griffith worked at the Tennessee Valley Authority (TVA), an electric utility, as a nuclear piping analyst, valve and heat exchanger specialist, maintenance engineer and later maintenance supervisor at a fossil plant, and quality manager. There his engineering roles included failure analysis of plant equipment....

William Henry, PhD, NCARB RGA Design Forensics LLC

Tennessee
Premises Liability, Disaster Recovery - Accident Investigation, Building Codes, ADA, Accessibility, Slip Trip & Fall, Forensic, Architecture, Engineering, E&O, Errors and Omissions, Construction Defects, Mold, Cruise Ship, Maintenance, Building Inspection, Insurance Claims, Disaster Recovery, Failure Analysis, Property Insurance
...Henry, our lead expert, utilizes three components in his case development: (1) a detailed timeline, (2) an analysis of the governing codes and documentation, and (3) the application of the facts to those governing codes. His reports and testimony are presented in a simple, clear manner that is easily understood. This approach has had a proven impact on the outcomes of past matters, whether in settlement, mediation, arbitration, or at trial. RGA Design Forensics’ main areas of expertise are premises liability, property insurance litigation, and architectural errors and omissions (E&O) claims. Premises Liability - Whether a slip trip & fall or some other incident, RGA works with both plaintiff and defense counsels to determine adherence to or deviation from governing codes, standards, and guidelines around the site. This information is vital in determining causality in a case....

Steve Scoville Scoville & Associates, Inc.

Nashville, Tennessee
Construction, Construction Defects - Construction Defects, Construction Scheduling, Construction Management, Building Codes, Healthcare/Commercial/ and Residential Construction, Construction Contracts, Construction Claims, Construction Planning, Insurance Claims Evaluation, Construction Cost Estimates
...In building design, construction, facilities management, and performance on different types of contracts, Scoville and Associates (S&A) provide services to attorneys representing defendants and plaintiffs, insurance companies and institutions, and private individuals. Experience in construction is extensive. Experience in legal cases is three, with one still awaiting trial. Services include reviewing contracts and project records to assess adherence to contractual obligations. Scoville & Associates, Inc. performs site surveys when an on-site review is needed: photographing and noting pertinent conditions. If instructed, the research includes reviews of court filings, codes, designs, contract documents, and correspondence. S&A Analyzes information gathered versus contracts, building codes, project-specific design requirements, and personal experience. S&A verbally communicates preliminary conclusions to the supervising attorney....

Dan Bawden, CAPS, CGP, CGR, GMB, GMR DanBawdenexpertwitness.com

Houston, Texas
Construction, Construction Defects - Cost of repairs, Stucco failures, Roof and flashing failures, Duty of care, Damage causation, Code compliance, Proper repair protocols, Materials and methods, Building, Remodeling, Performance standards, cost estimating, Residential Construction Performance Standards, Home repairs,
...Duties in his firm include design, specification-writing, estimating, quality control, and day-to-day construction management. His firm, Legal Eagle Contractors Company, has enjoyed an excellent reputation both online and in the Houston area for decades. Dan is a Past President of the Greater Houston Builders Association (GHBA). He is an active member, instructor and speaker in the GHBA. Dan rose to the top industry leadership position at the national level. After many years of serving on the Board of Directors at NAHB, he was asked to serve as Chairman of the NAHB Remodelers in 2019. He represented the Remodeling Industry across the country. Apparently, he did a great job. He was subsequently nominated and inducted into the NAHBR "Hall of Fame" in 2020. Very few contractors have received this honor. This recognition is awarded for making a lasting impact on the residential construction industry nationwide....

Tony DiNicola, AIA, RID, APA TONY DiNICOLA ARCHITECT

Fort Worth, Texas
Architecture, Slip Trip & Fall - Forensic Architecture, Architectural Design, Construction Defects, Design Defects, Accessibility Design, ADA, Fair Housing, Texas Accessibility Standards (TAS), Plan Reviews, Inspections, Fair Housing Design Standards, Cause and Origin, Water Intrusion, Roofing Failures, Building Codes, Zoning,
...DiNicola offers forensic consulting in the Following areas EXPERT WITNESS: Reports and Presentations, Certificates of Merit, Depositions and Testimony ANALYSIS OF ARCHITECTURAL SERVICES: Architect’s Standard of Care, Architect’s Errors and Omissions, Pre-Construction Services Facility Programing, Design, Bidding Services, Construction Services, Construction Administration and Post-Construction Services AMERICANS WITH DISABILITIES ACT: ADA Violations, Texas Accessibility Standards (Plan Reviews and Site Inspections), Site and Building Accessibility Compliance FAIR HOUSING: Compliance with Fair Housing design requirements CODES AND ORDINANCES: Compliance with Building Codes, Local Ordinances, Industry Standards, ADA and Fair Housing BUILDING FAILURES: Analysis of Construction and Design Defects, Cause and Origin and Failure Analysis Roofing Failures: Roofing design and detailing, evaluation of drainage conditions, code analysis, determination of cause and extent of water intrusion...

Michael Fiebig, RA, AIA, NCARB, LEED GA, CFPS, CEP Fiebig Architecture

Texas
Construction Defects, Premises Liability - Architecture, Construction, Construction Defect, Fire Protection, Fire Suppression, Fire-Resistive Assemblies, Residential Construction, Commercial Construction, Building Codes, Premises Liability, Slip & Fall, Trip & Fall.
Registered architect with NCARB certificate in twenty states (licensed in more states than are listed in this directory), with an active design and forensic practice. As a forensic architect, his experience includes among other things, performing analysis of standard of care in building design and construction projects; performing analyses of building systems including roofing systems, window and door systems, exterior wall cladding systems, waterproofing and foundation systems, with a specialization in fire-resistive assemblies and active fire-protection systems. His experience includes premises liability investigation and analysis of accident sites relating to the built environment, both indoors and outdoors. As a design architect, his practice includes traditional architectural practice including building design, building code analysis & application, and services during construction....

Justin Hall, MAS, PE Hall Engineering Group, Ltd

Texas
Engineering, Construction Defects - Civil Engineering, mechanical engineering, engineering, construction, construction fault, forensic engineering, structural failure, structural inspection. Licensed in AR, TX, OK, MO, KS, MS.
...With over 20 years of experience in engineering and forensic consulting, design, construction assessments, international codes and research, Justin Hall, PE has provided clients with structural analysis and design, condition assessment, damage investigations, failure analysis, construction consulting & management, and expert testimony. States include Arkansas, Missouri, Oklahoma, Texas, Tennessee, Louisiana and Mississippi....

David Levey David S. Levey, M.D., P.A.

Austin, Texas
Diagnostic Radiology, Neuroradiology - Radiology, Radiologist, Musculoskeletal, Neuroradiology, MRI, DTI, TBI, CT Scan, X-ray, Brain Injury, Medical Malpractice, Personal Injury, Insurance Defense, Defense, Plaintiff, Free Consultation, PET Scan, Orthopedic Radiology, MSK, Pediatric & Neonatal Radiology, Spinal Injury, Medical Expert
...He has personally designed a program for obtaining 3T DTI MRI brain imaging on potentially brain-injured patients, for which he uses qualitative and quantitative brain 3T MRI DTI imaging. He has evaluated brain injured patients throughout the US and Canada. Recently, Dr. Levey was the radiology medical expert in the U.S. v. Bergdahl military case, where brain injury evaluation w/ Brain MRI DTI was employed....

Fred B. Lott, AIA, ARA, CSI Fred Lott Architect

Texas
Architecture, Construction Defects - Architect & Engineer Negligence, Construction Defects, Fraudulent Change Orders, Construction License Agreement, Antitrust Complaint, Standard of Care Responsibility & Compliance, Warehouse Thermal Comfort, Bid Steering, Treachery & Self-Dealing Related to Professional Practice Industry Standards
...Expert Witness & Dispute Resolution 34 years Registered Architect 44 years Construction Executive 28 years Owner Representative 24 years Fred leverages his in-depth experience of leading cross-discipline teams of design & engineering professionals and construction management teams when presenting detailed opinions and support information in an understandable way. Fred’s work has included community boards, governing agencies, investors, General Services Administration - Offices of the Inspector General, FBI, multiple state courts (including Indiana, Illinois, California, Georgia, Florida, and New York), the New York County District Attorney’s Office (Labor Racketeering Unit, Construction Industry Strike Force), the New York City Office of Administrative Trials & Hearings, and the City of New York Police Department (District Attorney’s Office Squad)....

Aftab Sheikh, P.E., PMP Sheikh Engineers and Consulting, LLC

Pflugerville, Texas
Electrical Engineering, Fire - Transformer, motor, generator, UPS, circuit breaker, switchboard, electrical fire, electrical insulation failure, short circuit, fault current, Arch flash, fire alarm, field investigation.
...Duties include but not limitted to: equipment failure analysis, writing technical reports, writing business case, project budget preparation, project managment, review and recommend expert solutions, electrical saftey, energy savings, promotes clean energy systems design for the 130 acres of Travis County Correctional Complex and Travis County Jail. Worked internationally (Bangladesh, Malaysia, Brunei Darussalam and the USA). Experienced in applying British Standards, International Building Code, National Electrical Code (NEC), National Fire Alarm Code (NFPA), National Electrical Safety Code (IEEE SA) etc....

Gary L Woods, PhD Rice University Dept. of Electrical & Computer Engineering

Houston, Texas
Electrical Engineering, Electronics - Microelectronics, Integrated Circuits, Radio Frequency, Optics, Lasers, Electro-optics, optical fibers, Electronic Devices, Antennas, Semiconductors, Semiconductor Manufacturing, Microscopy
...I have professional experience in electronics, circuits, device physics, radio frequency circuits and systems, lasers, optics, fiber optics, embedded coding, semiconductor design, semiconductor manufacturing, internet of things, motor control, and electro-optical systems. I have experience in patent law from the engineering side: I am a co-inventor on more than a dozen patents. have owned the IP portfolio and strategy of one of my startup companies, and provide lectures on patents in my ECE classes. My teaching experience at Rice University includes courses in device physics, circuits, optics, and senior design. The latter course keeps me current in many areas of electrical engineering practice. I have never testified at trial. However, I have won numerous teaching awards at Rice, and I believe I would be persuasive in front of a jury.

Randy A Winters MatrixHCI, LLC

Saint George, Utah
Software Engineering, Computers - Cybersecurity, Software Architecture, Artificial Intelligence, Cryptocurrency / Blockchain, Speech & Face Recognition, ESI Protocol, Social Media Forensics, Biometric Identifiers, Code Review, Patent Infringement ,Trade Secret, IPR, PTAB, Claim Analysis, Forensic Data Extraction, BIPA
...- In addition to his blockchain development experience, he designed the first cryptocurrency arbitrage system....

Matthew Furlong, CBC, RBC Först Consulting Group

Middleburg, Virginia
Construction Defects, Construction - Forensic investigation, building pathology, failure analysis, technical reporting, construction claims, litigation support, insurance, building code, EIFs, stucco, building envelope, facades, rainscreen, infrared, moisture, structural capability, energy conservation, contract analysis.
...Furlong has 21 years of experience with construction, project coordination and design, remodeling, and field inspections of building systems for residential, and commercial low and high-rise properties. He has successfully completed more than 600 unique and custom projects while as a general contractor. His builder background experience ranges from high-end new custom home construction, interior renovations and additions, to green building and energy efficient homes, historical renovations, timber-framing, and creating elaborate custom interiors in prestigious estate-sized homes. This experience gives Mr. Furlong the unique qualifications to testify as an expert in construction matters. As a professional consultant, Mr. Furlong provides services in the forensic investigation field related to construction defects, Building Code compliance, contract review and analysis, construction delay analysis and investigation....

Mohamed E. Hassan, PhD, PE Hassan Consulting Group, LLC

Gainesville, Virginia
Construction, Construction Defects - Engineering Design, Building Codes, construction management, structural engineering, infrastructure engineering, reinforced concrete, steel structures, bridges, Structure engineer, foundations, piers, abutments, and soil analysis.
- 45 years construction design and management of commercial and residential projects. - 15 years Construction Expert Witness - 10 years of teaching experience in George Mason University, DeVry University and NVCC - 15 years of mediation and conflict resolution Mohamed Hassan, PhD, PE has 45 years of diversified experience in the construction industry for commercial and residential projects. He is the principal of Hassan Consulting Group, LLC specializing in designing and building a variety of projects. He was an adjunct professor at George Mason University, DeVry University, and Northern Virginia Community College. LICENSES: He is a licensed professional engineer in the states of Virginia and Texas. He is also licensed contractor in the state of Virginia and District of Colombia (Washington DC). He is certified by the Supreme Court of Virginia as a Mediator. He is admitted in Virginia, West Virginia and Washington DC Court Systems....

Tara L Pase Bramel Engineering, LLC

Virginia
Structural Engineering, Civil Engineering - Construction Defect, Concrete, Seismic, Retaining Walls, OSHA, Building Codes, Steel, Earthquake, Stormwater Management, Civil Engineering, Failure Analysis, Wood, Wind, Construction, Structural Engineering, Strength of Materials, Masonry, Foundations, Construction Accident, Design and Analysis
Civil/Structural Engineering Construction Defects Building Codes OSHA Failure Analysis Strength of Materials Concrete/Steel/Wood/Masonry Design Concrete/Steel/Wood/Masonry Analysis Seismic Design and Analysis Wind Design and Analysis Foundations and Retaining Structures Grading and Soil Properties Field Repair Designs Stormwater Management Component/Connection Design and Analysis Construction Cost Estimates Building Envelope (Moisture Barriers) Construction Management Registered Professional Engineer, State of New York, License No.087752 Registered Professional Engineer, State of Maryland, License No.42640 Registered Professional Engineer, Commonwealth of Virginia, License No.051210 Registered Professional Engineer, State of New Jersey, License No.24GE05239300

Captain Peter McGuiness American Maritime Information Service LLC

Vancouver, Washington
Maritime, Management - newbuilding sea trials, bridge resource management, watchkeeping, watchstanding, navigation, shiphandling, tanker operations, cruise ship operations, quality and safety management systems, ISM Code, ISPS Code, regulations for preventing collisions at sea (“Rules of the Road”), teaching and training
...EXPERIENCE -- Newbuilding sea trials shipmaster (over 100 sea trials in over 50 new ships) -- Operations, health, environment and safety superintendent -- Quality and safety management system lead auditor -- Shipmaster and officer in commercial merchant ships on international and US coastwise voyages -- Appointed shipmaster of a new refined products tanker in US coastwise service, at age thirty -- Served as second mate and chief mate on four maiden voyages, two on new trade routes for the respective shipowners EXPERTISE -- Command in newbuilding sea trials -- Bridge resource management, watchstanding, watchkeeping, navigation, shiphandling -- Petroleum tankship operations -- Tanker Management Self-Assessment 3 (TMSA3) -- Cruise ship operations including operation of their tender boats and rescue boats -- Design, administration and audit of quality management systems, safety management systems, and security management systems -- International Management Code for the Safe Operation...

Steven Wilcox

Seattle, Washington
Premises Liability, Dispute Resolution - Building construction, litigation, apartment, fire, damage, stair, starway, slip, fall, injury, public, private, accessibility, ADA, trip, ramp, sidewalk, forensic, government, inspection, investigation, dispute resolution, asbestos, lead, swimming pool, condominium, site development, case support.
...Our forensic analysis of investigation findings is based on design, construction methods, material applications, applicable codes, maintenace, alterations, and standards of care.

Mark R Webster, PE, MSME, MBA Webster Engineering, LLC

Hubertus, Wisconsin
Mechanical Engineering, Equipment & Machinery - Conveyors, Elevators, Material Lifts, Industrial Controls, Dynamic Analysis, Animations, Forensic Engineering, Intellectual Property, Freight Lifts, ASME Safety Standards, Failure Analysis, Hydraulics, Manufacturing, Products Liability, Lifting Systems, Material Handling, Machinery, Patents.
...Chair of ASME B20.1 Safety Standards for Conveyors and Related Equipment, Member of ASME Board on Safety Codes and Standards, member of the National Academy of Forensic Engineers. Engineering specialties include machine design, dynamic system analysis and animation (multi-body physics, motion analysis), hydraulic lifts and systems, heavy mechanical drives for lifting and other material handling applications, finite element analysis. Very active in ASME safety codes and standards.